Completion of ExpertiseFollowing Receipt of Objection Notice Sample Clauses

Completion of ExpertiseFollowing Receipt of Objection Notice. In the event of receipt by the Contractor of an Objection Notice in accordancewith Clause7.5, the Contractorshall: (a) take due account of all Defects,irrespectiveof their extent or nature, and other mattersraised in the Objection Notice; (b) assoon asreasonablypracticable,correct such Defectsand deficiencies,irrespective of their extent or nature, and complete the Works indicated in the Objection Notice so as to comply in all material respectswith the requirementsof this Agreement;and (c) issue to the Principal a second Provisional Completion Certificatesubstantially in the form of Annex D (Form of ProvisionalCompletion Certificate). The second Provisional Completion Certificate issued in accordance with Clause 7.6(c) shall include the Deliverable and adequate supporting documentation relevant to the Expertise Milestone attained and/or Deliverablecompleted. In the event no reasonsfor objection to the second ProvisionalCompletion Certificate exist, the Principal shall, within reasonable time following receipt of the second Provisional Completion Certificate, issue a Certificate of Provisional Acceptance in the form of Annex E (Form of Provisional Acceptance Certificate) and, subject to the provisionsof Clauses2.4 and 9.1(b)of this Agreement,the date of the Provisional Acceptance Certificate shall constitute Completion Date with respect to the relevant Expertise Milestone and/or Deliverable. For the avoidance of any doubt, the giving by the Principal of any Objection Notice under Clause7.5 or second Objection Notice under this Clause7.6 shall be without prejudice to and shall not relievethe Contractor from the obligation to pay any contractual penalty in accordancewith the provisions of Clause 10.2 or to pay Damages in accordance with the provisions Clause 10.3 of this Agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Completion of ExpertiseFollowing Receipt of Objection Notice

  • Notice of Objection Contractor may object to any action taken by NYSERDA pursuant to this Exhibit that prevents the commencement of the time in which interest will be paid by submitting a written notice of objection to NYSERDA. Such notice shall be signed and dated and concisely and clearly set forth the basis for the objection and be addressed to the Vice President, New York State Energy Research and Development Authority, at the notice address set forth in Exhibit B to this Agreement. The Vice President of NYSERDA, or his or her designee, shall review the objection for purposes of affirming or modifying NYSERDA‘s action. Within fifteen (15) working days of the receipt of the objection, the Vice President, or his or her designee, shall notify the Contractor either that NYSERDA‘s action is affirmed or that it is modified or that, due to the complexity of the issue, additional time is needed to conduct the review; provided, however, in no event shall the extended review period exceed thirty (30) working days.

  • Dispute Notice If there is a dispute between the parties, then either party may give a notice to the other succinctly setting out the details of the dispute and stating that it is a dispute notice given under this clause 17.1.

  • Response to Objections Each Party retains the right to respond to any objection raised by a Participating Class Member, including the right to file responsive documents in Court no later than five court days prior to the Final Approval Hearing, or as otherwise ordered or accepted by the Court.

  • Resolution of Disagreements Disputes arising under this Agreement will be resolved informally by discussions between Agency Points of Contact, or other officials designated by each agency.

  • Termination Notice and Procedure Any Covered Termination by the Company or the Executive (other than a termination of the Executive’s employment that is a Covered Termination by virtue of Section 2(b)) shall be communicated by a written notice of termination (“Notice of Termination”) to the Executive, if such Notice is given by the Company, and to the Company, if such Notice is given by the Executive, all in accordance with the following procedures and those set forth in Section 23: (a) If such termination is for disability, Cause or Good Reason, the Notice of Termination shall indicate in reasonable detail the facts and circumstances alleged to provide a basis for such termination. (b) Any Notice of Termination by the Company shall have been approved, prior to the giving thereof to the Executive, by a resolution duly adopted by a majority of the directors of the Company (or any successor corporation) then in office. (c) If the Notice is given by the Executive for Good Reason, the Executive may cease performing his duties hereunder on or after the date fifteen days after the delivery of Notice of Termination and shall in any event cease employment on the Termination Date. If the Notice is given by the Company, then the Executive may cease performing his duties hereunder on the date of receipt of the Notice of Termination, subject to the Executive’s rights hereunder. (d) The Executive shall have thirty days, or such longer period as the Company may determine to be appropriate, to cure any conduct or act, if curable, alleged to provide grounds for termination of the Executive’s employment for Cause under this Agreement pursuant to Section 1(f)(iii). (e) The recipient of any Notice of Termination shall personally deliver or mail in accordance with Section 23 written notice of any dispute relating to such Notice of Termination to the party giving such Notice within fifteen days after receipt thereof; provided, however, that if the Executive’s conduct or act alleged to provide grounds for termination by the Company for Cause is curable, then such period shall be thirty days. After the expiration of such period, the contents of the Notice of Termination shall become final and not subject to dispute.

  • Disagreement Any dissension between the parties other than a grievance defined in the agreement and other than a dispute defined in the Labour Code.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Notice of Change Grantee shall notify the Grantor if there is a change in Grantee’s legal status, federal employer identification number (FEIN), DUNS Number, UEI, XXX registration status, Related Parties, senior management or address. See 30 ILCS 708/60(a). If the change is anticipated, Grantee shall give thirty (30) days’ prior written notice to Grantor. If the change is unanticipated, Grantee shall give notice as soon as practicable thereafter. Grantor reserves the right to take any and all appropriate action as a result of such change(s).

  • Dispute Procedure (1) Unless otherwise provided in the Council's Constitution or in this Collective Agreement, any dispute within the registered scope of the Council shall be resolved as set out below: (a) The General Secretary of the Council shall, after consultation with the Secretary of any relevant Regional Chamber, decide whether any dispute referred to the Council must be dealt with by the Council or the Regional Chamber. (b) The Council shall, from time to time, adopt, by resolution, guidelines for the General Secretary of the Council to follow in the allocation of such disputes. (c) When any dispute is allocated to a Regional Chamber in terms of this clause, then such Regional Chamber shall have the same rights, powers and obligations as the Council.

  • Notice of Dispute The party wishing to commence the dispute resolution process must give written notice (Notice of Dispute) to the other parties of: (a) The nature of the dispute, (b) The alleged basis of the dispute, and (c) The position which the party issuing the Notice of Dispute believes is correct.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!