Conditions Precedent to Advances Notwithstanding any other provision of this Agreement or the Other Agreements and without affecting in any manner the rights of Lender under this Agreement, it is understood and agreed that Lender shall have no obligation to make any advance under this Agreement unless and until the following conditions have been, and continue to be, satisfied, all in form and substance reasonably satisfactory to Lender and its counsel:
(a) Lender shall have received, on or prior to the Closing Date unless otherwise indicated, the following documents:
(i) the Notes, duly executed and delivered;
(ii) evidence of the qualification and good standing of Borrower in each state in which it is required to be qualified to do business except where its failure to qualify or its lack of good standing would not have a material. adverse affect on Borrower or its ability to conduct its business as currently conducted;
(iii) certified copies of the resolutions of the Board of Directors of Borrower (a) authorizing the Loans and the Hedge Agreement, and (b) authorizing execution and delivery of this Agreement and the Other Agreements by officers of the Borrower;
(iv) certificates of the secretary of the Borrower certifying to the Lender the names of its officers, the offices that each holds, the authenticity of their signatures, and the completeness and accuracy of its articles of incorporation and bylaws;
(v) an opinion of Borrower’s counsel, duly executed and delivered; and
(vi) the Other Agreements, duly executed and delivered;
(b) Borrower shall have executed and delivered such additional documents and instruments as have been requested by Lender;
(c) the representations and warranties contained herein shall be true on and as of the Closing Date, and there shall exist on the Closing Date no Default or Event of Default;
(d) the advances on the terms and conditions herein provided (including the use by Borrower of the proceeds of the advances) shall not violate any applicable law or governmental regulation (including, without limitation, Regulations G, T, U and X of the Board of Governors of the Federal Reserve System) and shall not subject Lender to tax (other than income and franchise taxes) and Lender shall have received such certificates or other evidence as Lender may reasonably request to establish compliance with this condition; and
(e) all corporate and other proceedings taken or to be taken in connection with the transactions contemplated hereby and all documents incident thereto shall be in substance and form reasonably satisfactory to Lender and its counsel, and Lender and its counsel shall have received all such counterpart originals or certified or other copies of such documents as Lender or its counsel may reasonably request.
Conditions Precedent to All Advances (a) Each Advance under this Agreement and each reinvestment of Principal Collections pursuant to Section 2.7(d) (each, a “Transaction”) shall be subject to the further conditions precedent that:
(i) with respect to (A) any Loan Advance, the Collateral Manager shall have delivered to the Administrative Agent (with a copy to the Collateral Custodian) no later than 3:00 p.m. one (1) Business Day prior to the related Funding Date or (B) any Swingline Advance, the Collateral Manager shall have delivered to the Administrative Agent (with a copy to the Collateral Custodian) no later than 3:00 p.m. on the related Funding Date:
(1) the documents required by Section 2.2(b) and a Loan Schedule; and
(2) a Certificate of Assignment substantially in the form of Exhibit F containing such additional information as may be reasonably requested by the Administrative Agent and each Lender;
(ii) with respect to any reinvestment of Principal Collections permitted by Section 2.7(d), the Collateral Manager shall have delivered to the Administrative Agent (with a copy to the Collateral Custodian), no later than 3:00 p.m. on the Business Day prior to any such reinvestment, a Reinvestment Notice in the form of Exhibit A-3 and a Borrowing Base Certificate, executed by the Collateral Manager and the Borrower;
(b) On the date of such Transaction the following shall be true and correct and the Borrower and the Collateral Manager shall have certified in the related Borrower’s Notice that all conditions precedent to the requested Transaction have been satisfied and shall thereby be deemed to have certified that:
(i) The representations and warranties contained in Section 4.1 and Section 4.2 are true and correct in all respects on and as of such day as though made on and as of such day and shall be deemed to have been made on such day (other than any representation and warranty that is made as of a specific date);
(ii) No event has occurred, or would result from such Transaction or from the application of proceeds thereof, that constitutes an Event of Default, Default or Collateral Manager Default;
(iii) On and as of such day, after giving effect to such Transaction, the Availability is greater than or equal to zero;
(iv) On and as of such day, the Borrower and the Collateral Manager each has performed all of the covenants and agreements contained in this Agreement to be performed by such Person on or prior to such day;
(v) No Applicable Law prohibits or enjoins the making of such Advance by any Lender or the proposed reinvestment of Principal Collections; and
(vi) No Curable BDC Asset Coverage Event has occurred and is continuing.
(c) The Revolving Period End Date with respect to the all the Commitments or the Termination Date shall not have occurred;
(d) On the date of such Transaction, the Administrative Agent shall have received such other approvals, opinions or documents as the Administrative Agent may reasonably require;
(e) The Borrower and Collateral Manager shall have delivered to the Administrative Agent all reports required to be delivered as of the date of such Transaction including, without limitation, all deliveries required by Section 2.2;
(f) The Borrower shall have paid all fees then required to be paid and, without duplication of Section 2.11, shall have reimbursed the Lenders, the Collateral Custodian and the Administrative Agent for all fees, costs and expenses then required to be paid of closing the transactions contemplated hereunder and under the other Transaction Documents, including the reasonable attorney fees and any other legal and document preparation costs incurred by the Lenders, the Collateral Custodian and the Administrative Agent;
(g) The Borrower shall have received a copy of the related Approval Notice; and
(h) In connection with each Transaction, the Borrower shall have delivered to the Collateral Custodian (with a copy to the Administrative Agent) on the date of the related Transaction, an emailed copy of the duly executed original promissory notes for each such Loan in respect of which a promissory note is issued (or, in the case of any Noteless Loan, a fully executed assignment agreement), and, if any Loans are closed in escrow, a certificate (in the form of Exhibit J) from the closing attorneys of such Loan confirming the possession of the Required Loan Documents; provided that, notwithstanding the foregoing, the Borrower shall cause the Loan Checklist and the Required Loan Documents to be in the possession of the Collateral Custodian within ten (10) Business Days of any related Advance Date with respect to any Loan. The failure of the Borrower to satisfy any of the foregoing conditions precedent in respect of any Advance shall give rise to a right of the Administrative Agent, which right may be exercised at any time on the demand of the Required Lenders, to rescind the related Advance and direct the Borrower to pay to the Administrative Agent for the benefit of the Lenders an amount equal to the Advances made during any such time that any of the foregoing conditions precedent were not satisfied.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Conditions to Advances The obligation of Lender to make each Advance hereunder, shall be subject to the prior or simultaneous occurrence or satisfaction of each of the following conditions:
(a) The Loan Documents shall be and remain outstanding and enforceable in accordance with their terms, all as required hereunder.
(b) Lender shall have received a title report dated within two (2) days of the requested Advance from the Title Company showing no state of facts (other than the Permitted Exceptions) objectionable to Lender, including, but not limited to, a showing that title to the Land is vested in Global and that no claim for mechanics’ or materialmen’s liens has been filed against the Mortgaged Property.
(c) The representations and warranties made by Borrower, as contained in this Agreement and in all other Loan Documents shall be true and correct as of the date of each Advance; and if requested by Lender, Borrower shall give to Lender a certificate to that effect.
(d) The covenants made by Borrower to Lender, as contained in this Agreement and in all other Loan Documents shall have been fully complied with, except to the extent such compliance may be limited by the passage of time or the completion of construction of the Improvements.
(e) The Improvements shall not have been materially injured, damaged or destroyed by fire or other uninsured casualty, nor shall any part of the Mortgaged Property be subject to condemnation proceedings or negotiations for sale in lieu thereof.
(f) Borrower shall have complied with all requirements of the Inspecting Person and all Governmental Authorities.
(g) There shall exist no formal claim or dispute between Contractor and any contractor, subcontractor or materialmen as to monies owed in connection with any labor or materials furnished in connection with the construction of the Improvements.
(h) There shall exist no default or breach by any obligated party (other than the Lender) under the Loan Documents, provided however, to the extent that any grace or cure period is applicable to such a default or breach, the Lender shall be under no obligation to make an Advance unless and until said default or breach is cured to the reasonable satisfaction of the Lender.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.
Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.
Conditions to All Advances The obligation of each Lender to participate in any Advance, including the initial Advance, shall also be subject to the satisfaction of the conditions precedent that on the date of such Advance:
(a) the Administrative Agent shall have received a properly completed Disbursement Claim signed by an Authorized Officer of each of the Borrower and Ericsson and confirming the accuracy of the statements applicable to the Borrower in clause (b);
(b) each of the representations and warranties of the Borrower and each other Loan Party contained in this Agreement, the other Loan Documents or in any document or instrument delivered pursuant to or in connection with this Agreement or any other Loan Document is true and correct in all material respects immediately prior to, and after giving effect to, the making of such Advance and the application of the proceeds therefrom, as though made on and as of such date (except to the extent of changes resulting from transactions contemplated or permitted by this Agreement and the other Loan Documents and changes occurring in the ordinary course of business that singly or in the aggregate are not materially adverse, and to the extent that such representations and warranties relate expressly to an earlier date);
(c) no event has occurred and is continuing, or would result from making such Advance or from the application of the proceeds therefrom, that constitutes an Event of Default, Potential Event of Default or default under any other Loan Document;
(d) no change shall have occurred in any law or regulations thereunder or interpretations thereof that in the reasonable opinion of any Lender would make it illegal for such Lender to make such Advance and no order of any court or Governmental Body has been entered prohibiting the consummation of the transactions contemplated by the Loan Documents;
(e) each Lender shall have received such statements in form and substance reasonably satisfactory to such Lender as such Lender shall require for the purpose of compliance with any applicable regulations of the Comptroller of the Currency or the Board of Governors of the Federal Reserve System;
(f) the Administrative Agent shall have received such other approvals, opinions or documents as any Lender through the Administrative Agent may reasonably request;
(g) the Administrative Agent shall:
(i) have received evidence reasonably satisfactory to the Administrative Agent showing the aggregate amount of Eligible Swedish Goods and Services that have been incurred by the Borrower and its Subsidiaries through the date of such Advance;
(ii) have received the EKN Guarantee for each previous Advance made at least one month before the date of the requested Advance, each duly executed by EKN and in form and substance satisfactory to each Lender; and
(iii) have received evidence satisfactory to it that all premia and fees, if any, outstanding to EKN in respect of the EKN Guarantees for each previous Advance shall have been unconditionally and irrevocably paid in full; and
(h) no events or circumstances described in the first paragraphs before the provisos to Section 12.1(f)(i), (f)(ii) of (f)(iii) in relation to any Grandparent Debt Default shall have occurred and be subsisting.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State.
4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor.
4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor.
4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto.
4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project.
4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
