Consolidation with Third Party Disputes Sample Clauses

Consolidation with Third Party Disputes. (a) Subject to Section 4.4(d), if either Party is involved in an arbitration in the Province of Alberta with a third party (a "Third Party Arbitration"), and if such Third Party Arbitration involves common factual or legal issues (including common issues of damages) which are also the subject of a Dispute between the Parties for which a Notice of Dispute has been given, then any arbitration of the Dispute between the Parties which includes those common factual, legal or damages issues (a "Project Agreement Arbitration") shall be stayed, consolidated or joined with the Third Party Arbitration(s) but only if the City, Project Co and the other parties all agree or, failing their agreement, if a court in the Province of Alberta on application considers it just and convenient in all the circumstances that the Project Agreement Arbitration should be stayed or consolidated or joined with the Third Party Arbitration. (b) Subject to Section 4.4(d), if either Party is involved in litigation in the Province of Alberta with a third party ("Third Party Litigation") and if: (i) such Third Party Litigation involves common factual or legal issues (including common issues of damages) which are the subject of a Project Agreement Arbitration; and (ii) one of the Parties is brought directly into the Third Party Litigation as a Party to that litigation, then on the application of either Party to the court in the Province of Alberta having jurisdiction the court may, if it determines that it is just and convenient in all the circumstances, order a stay of either or both the Project Agreement Arbitration proceeding and the Third Party Litigation, or order a joinder of the Project Agreement Arbitration and the Third Party Litigation. If such joinder is ordered, the Project Agreement Arbitration and the Third Party Litigation ordered to be joined by the court shall be determined by that court or by another court in the Province of Alberta such that the Project Agreement Arbitration and the Third Party Litigation shall be resolved in one forum. For purposes of the foregoing, joinder of the Project Agreement Arbitration and the Third Party Litigation shall be construed to include stays and conditional stays of issues in the Project Agreement Arbitration pending the commencement and completion of third party proceedings by one or both of the Parties in the Third Party Litigation. (c) In considering whether to order a stay, consolidation or joinder of a Project Agreement Arbitration w...
Sample 1
AutoNDA by SimpleDocs
Consolidation with Third Party Disputes. If either party is involved in an arbitration or litigation proceeding in the Province of Saskatchewan with a third party (“Third Party Action”) and if such Third Party Action involves common factual or legal issues (including common issues of damages) which are also the subject of a Dispute between the parties for which a Dispute Notice has been given, then any arbitration or litigation of the Dispute between the parties which includes those common factual, legal or damages issues (“DBFOM Agreement Action”) shall be stayed, consolidated or joined with the Third Party Action(s) but only if the City, Project Co and the third party all agree or, failing their agreement, if a court in the Province of Saskatchewan on application considers it just and convenient in all the circumstances that the DBFOM Agreement Action should be stayed or consolidated or joined with the Third Party Action. Nothing in this Schedule 6 in any way limits either party’s ability to make a third party claim against the other for contribution or indemnity in respect of the first party’s liability or potential liability to a third party.
Sample 1

Related to Consolidation with Third Party Disputes

  • COOPERATION WITH THIRD PARTIES The Contractor shall be responsible for fully cooperating with any third party, including but not limited to other Contractors or Subcontractors of the Authorized User, as necessary to ensure delivery or performance of Product.

  • Cooperation With Regard to Litigation Executive agrees to cooperate with the Company, during the term and thereafter (including following Executive’s termination of employment for any reason), by making himself available to testify on behalf of the Company or any subsidiary or affiliate of the Company, in any action, suit, or proceeding, whether civil, criminal, administrative, or investigative, and to assist the Company, or any subsidiary or affiliate of the Company, in any such action, suit, or proceeding, by providing information and meeting and consulting with the Board or its representatives or counsel, or representatives or counsel to the Company, or any subsidiary or affiliate of the Company, as may be reasonably requested and after taking into account Executive’s post-termination responsibilities and obligations. The Company agrees to reimburse Executive, on an after-tax basis, for all reasonable expenses actually incurred in connection with his provision of testimony or assistance.

  • Notice and Defense of Third Party Claims Promptly following the earlier of (a) receipt of notice of the commencement by a third party of any Action against or otherwise involving any Indemnified Party or (b) receipt of information from a third party alleging the existence of a claim against an Indemnified Party, in either case, with respect to which indemnification may be sought pursuant to this Agreement (a “Third Party Claim”), the Indemnified Party shall give the Indemnifying Party written notice thereof. The failure of the Indemnified Party to give notice as provided in this Section 6.07 shall not relieve the Indemnifying Party of its obligations under this Agreement, except to the extent that the Indemnifying Party is materially prejudiced by such failure to give notice. Within thirty (30) days after receipt of such notice, the Indemnifying Party shall, by giving written notice thereof to the Indemnified Party, (a) acknowledge, as between the parties hereto, liability for, and at its option elect to assume the defense of such Third Party Claim at its sole cost and expense or (b) object to the claim of indemnification set forth in the notice delivered by the Indemnified Party pursuant to the first sentence of this Section 6.07 setting forth the grounds therefor; provided that if the Indemnifying Party does not within the same thirty (30) day period give the Indemnified Party written notice acknowledging liability or objecting to such claim and setting forth the grounds therefor, the Indemnifying Party shall be deemed to have acknowledged, as between the parties hereto, its liability to the Indemnified Party for such Third Party Claim. Any contest of a Third Party Claim as to which the Indemnifying Party has elected to assume the defense shall be conducted by attorneys employed by the Indemnifying Party and reasonably satisfactory to the Indemnified Party; provided that the Indemnified Party shall have the right to participate in such proceedings and to be represented by attorneys of its own choosing at the Indemnified Party’s sole cost and expense. If the Indemnifying Party assumes the defense of a Third Party Claim, the Indemnifying Party may settle or compromise the claim without the prior written consent of the Indemnified Party if such settlement or compromise is solely for monetary damages for which the Indemnifying Party shall be responsible for; in all other events, the Indemnifying Party may not agree to any settlement or compromise without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld or delayed. If the Indemnifying Party does not assume the defense of a Third Party Claim for which it has acknowledged liability for indemnification under Article VI, the Indemnified Party may require the Indemnifying Party to reimburse it on a current basis for its reasonable expenses of investigation, reasonable attorney’s fees and reasonable out-of-pocket expenses incurred in defending against such Third Party Claim, and the Indemnifying Party shall be bound by the result obtained with respect thereto by the Indemnified Party; provided that the Indemnifying Party shall not be liable for any settlement effected without its consent, which consent shall not be unreasonably withheld or delayed. The Indemnifying Party shall pay to the Indemnified Party in cash the amount for which the Indemnified Party is entitled to be indemnified (if any) within 15 days after the final resolution of such Third Party Claim (whether by the final nonappealable judgment of a court of competent jurisdiction or otherwise), or, in the case of any Third Party Claim as to which the Indemnifying Party has not acknowledged liability, within 15 days after such Indemnifying Party’s objection has been resolved by settlement, compromise or the final nonappealable judgment of a court of competent jurisdiction.

  • Third Party Dispute Resolution The Consulting Firm shall (i) consider only the items that are then disputed by the parties, (ii) shall be bound by the terms of the Agreement and (iii) shall only make a determination of such disputed matters in favor of the proposal made by the Purchasers or the Sellers (as may be presented by each party to the Consulting Firm in writing, which shall be shared with the other party) and shall not make an independent proposal. The Consulting Firm shall prepare a written determination of any disputed matters and deliver the determination to the Purchasers and the Sellers within fifteen (15) Business Days after the date the Consulting Firm is engaged. Each party shall cooperate fully with the Consulting Firm, including by using reasonable best efforts to provide the information, data and work papers to the extent permitted by applicable Law, so as to enable the Consulting Firm to make a determination of the disputed items as quickly as practicable. The Corrective Action Plan shall be finalized in accordance with the Consulting Firm’s determination of the disputed matters.

  • Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions: (i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim. (ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed. (iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.

  • Infringement and Litigation 11.1 Each party shall promptly notify the other in writing in the event that it obtains knowledge of infringing activity by third parties, or is sued or threatened with an infringement suit, in any country in the LICENSED TERRITORY as a result of activities that concern the LICENSED PATENTS, and shall supply the other party with documentation of the infringing activities that it possesses. 11.2 During the TERM of this Agreement: (a) LICENSEE shall have the first right (but not the obligation) to defend the LICENSED PATENTS against infringement or interference in the FIELD and in the LICENSED TERRITORY by third parties. This right includes bringing any legal action for infringement and defending any counter claim of invalidity or action of a third party for declaratory judgment for non-infringement or non-interference. If, in the reasonable opinion of LICENSEE’s counsel, YALE is required to be a named party to any such suit for standing purposes, LICENSEE may join YALE as a party; provided, however, that (i) YALE shall not be the first named party in any such action, (ii) the pleadings and any public statements about the action shall state that the action is being pursued by LICENSEE and that LICENSEE has joined YALE as a party; and (iii) LICENSEE shall keep YALE reasonably apprised of all developments in any such action. LICENSEE may settle such suits solely in its own name and solely at its own expense and through counsel of its own selection; provided, however, that no settlement shall be entered without YALE’s prior written consent, such consent not to be unreasonably withheld. Without limiting the foregoing, YALE may withhold its consent to any settlement that would in any manner affect the validity, scope or enforceability of any LICENSED PATENT. LICENSEE shall bear the expense of such legal actions. Except for providing reasonable assistance (including joining such actions as described above), at the request and expense of LICENSEE, YALE shall have no obligation regarding the legal actions described in Article 11.2 unless required to participate by law. However, YALE shall have the right to participate in any such action through its own counsel and at its own expense. Any recovery shall first be applied to LICENSEE’s out of pocket expenses and second shall be applied to YALE’s out of pocket expenses, including legal fees. YALE shall recover [***]% of any excess recovery over those expenses. (b) In the event LICENSEE fails to initiate and pursue or participate in the actions described in Article 11.2(a) or in lieu of such actions to initiate negotiations for a sublicense of the infringer, and the infringement has not otherwise abated, within [***] of notification of infringement from YALE, YALE may, in its sole discretion, convert the LICENSE granted in Article 3 to a non-exclusive license. Additionally, YALE shall have the right to initiate legal action such as that described in Article 11.2(a) at its own expense. If, in the reasonable opinion of YALE’s counsel, LICENSEE is required to be a named party to any such suit for standing purposes, YALE may join LICENSEE as party plaintiff to uphold the LICENSED PATENTS, provided, however, that YALE shall keep LICENSEE reasonably apprised of all developments in any such action. In such case, LICENSEE shall provide reasonable assistance to YALE if requested to do so, at YALE’s expense. YALE may settle such actions solely through its own counsel any recovery shall be retained by YALE. YALE may terminate the LICENSE in the country where such legal action is taken. (c) In the event LICENSEE is permanently enjoined from exercising its LICENSE under this Agreement pursuant to an infringement action brought by a third party, or if both LICENSEE and YALE elect not to undertake the defense or settlement of a suit alleging infringement for a period of [***] from notice of such suit, then either party shall have the right to terminate this Agreement in the country where the suit was filed with respect to the LICENSED PATENT following [***] written notice to the other party in accordance with the terms of Article 15.

  • Third Party Litigation In the event that a Third Party institutes a patent or other infringement suit against any of NovaDel, PAR or HANA or any of its respective Affiliates during the Term, alleging manufacture, use or sale of a Licensed Product in the Territory, infringes one or more patent or other intellectual property rights held by such Third Party (an “Infringement Suit”), the Parties shall cooperate with one another in defending such suit. PAR, as the NDA holder, shall have the first right to direct and control, at its expense, any Infringement Suit (including settlement negotiations, settlement or compromise thereof) to the extent that it relates to the manufacture, use or sale of a Licensed Product but does not implicate the Licensed Technology or Licensed Process. In the event that the Infringement Suit relates to the use of the Licensed Technology or Licensed Process, NovaDel shall have the first right to direct and control, at its expense, any such Infringement Suit (including settlement negotiations, settlement or compromise thereof). To the extent that any amounts become payable to any Third Party as a result of such action, whether through judgment or settlement, then PAR shall, unless HANA is jointly promoting and commercializing the Licensed Product pursuant to Section 2.4 and subject to Section 12.2, bear [***] percent ([***]%) of such amounts with respect to the Exploitation of the Licensed Product; provided, however, that PAR shall have the right to credit [***] percent ([***]%) of any amounts paid by PAR through judgment or settlement with respect to such country against the royalty payments to be paid by PAR to HANA with respect to the sale of the Licensed Product under Section 6.3; provided further, however, that no royalty payment when due, regardless of the amount or number of credits available to PAR shall be reduced by more than [***] percent ([***]%) of the amounts otherwise owed pursuant to Section 6.3 in any calendar quarter. Credits not exhausted in any calendar quarter may be carried into future calendar quarters. Notwithstanding the foregoing, in the event that no payments are due or owing, or contemplated to be due or owing, by PAR to HANA under Article 6 with respect to the sale of the Licensed Product, then NovaDel shall pay to PAR such amount owed to a Third Party up to a cap of [***]% of such amount owed to such Third Party, less any amount already credited to PAR under this Section 10.3. Notwithstanding the foregoing, NovaDel shall have no obligation under this Section 10.3 for any costs, expenses or damages that are paid or payable to a Third Party as a result of an actual or alleged infringement by PAR or HANA to the extent such costs, expenses or damages result from the use of a Product Trademark.

  • Pending Litigation or Other Proceedings There is no pending or, to the best of the Backup Servicer’s Knowledge, threatened action, suit, proceeding or investigation before any court, administrative agency, arbitrator or governmental body against or affecting the Backup Servicer which, if decided adversely, would materially and adversely affect (i) the condition (financial or otherwise), business or operations of the Backup Servicer, (ii) the ability of the Backup Servicer to perform its obligations under, or the validity or enforceability of this Indenture or any other documents or transactions contemplated under this Indenture, (iii) any property or title of any Obligor to any property or (iv) the Indenture Trustee’s ability to foreclose or otherwise enforce the Liens of the Timeshare Loans.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Defense of Third Party Claims In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!