Construction General Conditions Costs Sample Clauses

Construction General Conditions Costs. (a) Construction General Conditions Costs shall be reimbursed as they are incurred by the CM and only to the extent that such costs are itemized in the CM’s monthly invoice submitted by the CM for the preceding month in accordance with the Contract Documents. The CM shall submit to DCAMM with each invoice complete backup documentation in sufficient detail acceptable to DCAMM for all invoiced Construction General Conditions Costs. Personnel costs included in the Construction General Conditions Costs shall be based solely on the number of hours worked by the CM’s personnel and rates as set forth in the GMP Amendment (or, if applicable, an Early Package Amendment) for the time and rates shown as Approved by DCAMM. Throughout the duration of the Project, the total amount paid to the CM for Construction General Conditions Costs shall not exceed the amount for Construction General Conditions Costs shown in the GMP Amendment (or, if applicable, an Early Package Amendment) or the actual costs incurred by CM for such items, whichever is less. When submitting the final application for payment, in the event that the total costs for Construction General Conditions Costs incurred by the CM is less than the amount shown in the GMP Amendment (or, if applicable, an Early Package Amendment) for Construction General Conditions Costs, the GMP (or, if applicable Early Package Maximum Price) shall be reduced by an amount equal to the sum of the savings realized in the total Construction General Conditions Costs plus the CM Fee on such amount. If the total amount of actual Construction General Conditions Costs incurred by the CM exceeds the amount shown in the GMP Amendment (or, if applicable, an Early Package Amendment) for Construction General Conditions Costs, the excess costs shall be borne by the CM and shall not be reimbursed by DCAMM.
Sample 1
AutoNDA by SimpleDocs
Construction General Conditions Costs items to be included as allowances in the GMP in accordance with the Contract. Amounts for any such allowance items shall be negotiated and established as part of the GMP Amendment. Allowance Item Description 4
Sample 1

Related to Construction General Conditions Costs

  • General Conditions Costs Construction Manager is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from the Owner through Substantial Completion of the Project plus thirty (30) calendar days. Construction Manager is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion must be approved in advance by the Owner. Allowable General Conditions items are identified below and by attached exhibit. These items shall be included in the General Conditions cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the schedule of values. Items not specifically included below or in the exhibit will not be allowed as a General Condition costs.

  • For General Conditions Costs Contractor’s Application for Payment shall be submitted on a Schedule of Values approved by the Owner and include complete copies of all receipts, invoices with check vouchers or other evidence of payment, payrolls, and any and all other evidence which Owner or its designated representatives shall deem necessary to support the amount requested. This information is subject to audit and payment for these costs is dependent on Owner’s receipt of accurate and complete records of all transactions. Owner may reduce the amount requested for General Conditions Costs in any Application for Payment if Owner, in its good faith judgment, determines that the unpaid balance of the General Conditions line item in the Schedule of Values is not sufficient to fund necessary General Conditions Costs for the remainder of the Project.

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:

  • Project Construction Budget The project construction cost allowance specifically stated in writing as the ‘revised’ or ‘current’ ‘Project Construction Budget’ by the Trustees at each applicable phase of plan development.

  • Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.

  • BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply:

  • General Conditions (i) Each party will make each payment or delivery specified in each Confirmation to be made by it, subject to the other provisions of this Agreement.

  • Application of General Conditions These General Conditions set forth the terms and conditions generally applicable to the Development Grant Agreement to the extent and subject to any modifications set forth in such agreement.”

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

Time is Money Join Law Insider Premium to draft better contracts faster.