Construction Phase Changes; Adjustment of Contract Price Sample Clauses

Construction Phase Changes; Adjustment of Contract Price. The Contract Price for the Basic Services for an Assigned Project is not subject to adjustment unless there are Changes authorized by the District during the Construction Phase of an Assigned Project which are not the result of errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services for the Assigned Project. If services of the A/E or Sub-Consultants are required in connection with Changes during the Construction Phase of an Assigned Project which do not result from errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services for an Assigned Project, the Contract Price for an Assigned Project will be adjusted by an amount equal to or lesser of percent ( %) of the Construction Costs of such Changes or the time of the A/E or Sub-Consultants reasonably necessary to complete design and related services for such Changes, multiplied by the applicable hourly rate(s) set forth in the Rate Schedule for the Assigned Project. If a Change during the Construction Phase of an Assigned Project is the result of errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services, services required of the A/E or its Sub-Consultants in connection with such Change shall not result in adjustment of the Contract Price for the Assigned Project.
Sample 1
AutoNDA by SimpleDocs
Construction Phase Changes; Adjustment of Contract Price. The Contract Price for the Basic Services for an Assigned Project is not subject to adjustment unless there are changes authorized in writing by the District for an Assigned Project which are not the result of errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services for the Assigned Project. If services of the A/E or Sub-Consultants are required in connection with such changes during an Assigned Project which do not result from errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services for an Assigned Project, the Contract Price for an Assigned Project will be adjusted by an amount to be approved by the District Project team at the District’s sole discretion, in an amount reasonably necessary to complete design and related services for such changes. This amount will be based, at least in part, on any applicable hourly rate(s) set forth in the Rate Schedule for the Assigned Project. If a change during an Assigned Project is the result of errors, omissions or other defects in the Design Documents or failures of the A/E or Sub-Consultants to timely and completely perform the Basic Services, services required of the A/E or its Sub-Consultants in connection with such change shall not result in adjustment of the A/E Contract Price for the Assigned Project and shall be borne solely by the A/E.
Sample 1
Construction Phase Changes; Adjustment of Contract Price. The Contract Price for the Basic Services for an Assigned Project is not subject to adjustment unless there are Changes authorized by the District during the Construction Phase of an Assigned Project which are not the result of errors, omissions or other defects in the Design Documents or failures of the Architect or Design Consultants to timely and completely perform the Basic Services for the Assigned Project. If services of the Architect or Design Consultants are required in connection with Changes during the Construction Phase of an Assigned Project which do not result from errors, omissions or other defects in the Design Documents or failures of the Architect or Design Consultants to timely and completely perform the Basic Services for an Assigned Project, the Contract Price for an Assigned Project will be equitably adjusted to reflect the additional services provided. If a Change during the Construction Phase of an Assigned Project is the result of errors, omissions or other defects in the Design Documents or failures of the Architect or the Design Consultants to timely and completely perform the Basic Services, services required of the Architect or the Design Consultants in connection with such Change shall not result in adjustment of the Contract Price for the Assigned Project.
Sample 1

Related to Construction Phase Changes; Adjustment of Contract Price

  • Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:

  • Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract.‌ If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.

  • Contract Price Adjustment The basis upon which the Contract Price shall be adjusted is as set out in paragraph 9.2 of Schedule IVB.

  • Construction Phase Part 1 –

  • Adjustment of Contract Notwithstanding any other provisions of this contract, STATE may, pursuant to Oregon law, make adjustments in the contract when major catastrophes or significant changes in state or federal law after the date of this contract materially affect the volume and value of timber, or project work to be done, as specified in the section titled, "Project Work," under the contract. Major catastrophes or events beyond the reasonable control of the parties are defined as windstorms, floods, fire, or other acts of God, or significant changes in state or federal law, which are beyond the control of PURCHASER and in no way connected with negligent acts or omissions of PURCHASER, its officers, employees, agents, or subcontractors. Market conditions shall not be considered a reason for contract adjustments. Such adjustments may be made to place the parties in their original status under the contract insofar as possible; provided, however, that any loss or cost to PURCHASER is in no way recoverable from third parties by PURCHASER and that PURCHASER make written application to STATE within 30 days after discovery of the damage done by the catastrophe. If, prior to acceptance of project work, a catastrophe (as defined above) caused by a single event results in additional project work for PURCHASER involving an additional estimated cost of more than: (1) $500 for sales less than one-half million board feet; (2) $1,000 for sales of one-half million to three million board feet; or

  • C1 Contract Price C1.1 In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).

  • Construction Phase Payments 10.3.1 Payments for Construction Phase Services shall be made as provided for in the UGSC and Owner’s Specifications. All payment requests shall be submitted through e- Builder® with a Schedule of Values and include all required attachments. Payment for approved Change Orders shall be made as part of Contractor’s Application for Payment. Failure to submit a Prime Contractor Progress Assessment Report form with each Application for Payment will cause rejection of the application by Owner and its return to Contractor.

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

  • Construction Budget The total amount indicated by the District for the Project plus all other costs, including design, construction, administration, financing, and all other costs.

  • Construction Cost Adjustment Contracting Officer, as provided in B5.21, B5.212, B5.251, B5.252, and B5.253, shall adjust Specified Road construction cost estimates in the Schedule of Items and show the adjustments as credits or debits to Timber Sale Account in the month when the road segment is accepted.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!