Construction Properties Sample Clauses

Construction Properties. Subject to the terms and conditions of this Lease, on the Acquisition Date for each Construction Property (i) the Lessor shall purchase a fee interest in the relevant parcel of Land, or the Lessee shall convey a ground leasehold interest in such parcel of Land to the Lessor pursuant to a Ground Lease, and (ii) the Lessor shall demise and lease to the Lessee hereunder for the Lease Term applicable thereto the Lessor's interest in such Land together with any Improvements which then may be located thereon or thereafter may be constructed thereon pursuant to the Construction Agency Agreement or this Lease, and the Lessee hereby agrees to lease from the Lessor for such Lease Term, the Lessor's interest in such Land together with the Lessor's interest in such Improvements.
Sample 1
AutoNDA by SimpleDocs
Construction Properties. In addition to the conditions specified in (a) and (b) above, the occurrence of the Acquisition Date with respect to each Construction Property is subject to the following conditions precedent:
Sample 1
Construction Properties. Each Prime Construction Contract for a Construction Property provides for the Construction of the Improvements described on the Plans and Specifications for such Construction Property, upon the Land described in the Deed or Ground Lease for such Construction Property for a fixed price or a guaranteed maximum price on or before the expiration of the Construction Period for such Construction Property, and contains a retainage provision withholding an amount not less than ten percent (10%) of the fixed or guaranteed maximum price to be paid by Construction Agent thereunder until the satisfactory completion of the services to be provided by the Prime Contractor thereunder. All Governmental Actions (including building, demolition and environmental permits), easements and rights-of-way required for the Construction of the Improvements on any Construction Property in accordance with the Plans and Specifications therefor and the Construction Agency Agreement have either been obtained from the appropriate Governmental Authorities having jurisdiction or from private parties, as the case may be, or will be obtained from the appropriate Governmental Authorities having jurisdiction or from private parties, as the case may be, at or before the time required by all Requirements of Law and otherwise in a manner so as not to impede the Substantial Completion of such Construction on or before the expiration of the Construction Period for such Construction Property.
Sample 1
Construction Properties. If a Casualty or Condemnation shall affect any Construction Property for which the Lease Term has not commenced, the terms of the Construction Agency Agreement shall apply. ARTICLE XX
Sample 1
Construction Properties. (i) Each EPC Construction Contract, in the case of EPC Construction Property, will provide for construction, on a turn-key basis, of the Improvements thereto for a fixed price or a guaranteed maximum price on or before a date certain and will contain customary retainage provisions. (ii) (A) Each GC Construction Contract, in the case of GC Construction Property, will provide for construction of that portion of the Improvements to be built pursuant thereto for a fixed price or a guaranteed maximum price on or before a date certain and will contain customary retainage provisions.
Sample 1
Construction Properties. Notwithstanding anything to the contrary in this SECTION 27, the Lessee's obligation to indemnify any Indemnitee for any Claim or Imposition relating to a Construction Property during the Construction Period applicable thereto shall be subject to the provisions of SECTION 2.9 of the Construction Agency Agreement.
Sample 1
Construction Properties. Each Construction Property will be subjected to the terms of this Agreement upon the execution and delivery of a Construction Agency Agreement Supplement on the Acquisition Date therefor.
Sample 1
AutoNDA by SimpleDocs
Construction Properties 
Sample 1Sample 2Sample 3

Related to Construction Properties

  • The Properties Attached hereto as Schedule I is the description of certain Land (the "Subject Property"). Effective upon the execution and delivery of this Lease Supplement by Lessor and Lessee, such Land, together with any Building and other improvements thereon or which thereafter may be constructed thereon shall be subject to the terms and provisions of the Lease and Lessor hereby grants, conveys, transfers and assigns to the Related Lessee those interests, rights, titles, estates, powers and privileges provided for in the Lease with respect to the Subject Property.

  • Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.

  • Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

  • Borrowing Base Properties (a) Except where the failure to comply with any of the following would not have a Material Adverse Effect, each of Parent and Borrower shall, and shall use commercially reasonable efforts to cause each other Loan Party or the applicable tenant, to: (b) Pay all real estate and personal property taxes, assessments, water rates or sewer rents, ground rents, maintenance charges, impositions, and any other charges, including vault charges and license fees for the use of vaults, chutes and similar areas adjoining any Borrowing Base Property, now or hereafter levied or assessed or imposed against any Borrowing Base Property or any part thereof (except those which are being contested in good faith by appropriate proceedings diligently conducted). (c) Promptly pay (or cause to be paid) when due all bills and costs for labor, materials, and specifically fabricated materials incurred in connection with any Borrowing Base Property (except those which are being contested in good faith by appropriate proceedings diligently conducted), and in any event never permit to be created or exist in respect of any Borrowing Base Property or any part thereof any other or additional Lien or security interest other than Liens permitted by Section 8.01. (d) Operate the Borrowing Base Properties in a good and workmanlike manner and in all material respects in accordance with all Laws in accordance with such Loan Party’s prudent business judgment. (e) Cause each other Loan Party to, to the extent owned and controlled by a Loan Party, preserve, protect, renew, extend and retain all material rights and privileges granted for or applicable to each Borrowing Base Property.

  • Real Properties The Company does not have an interest in any real property, except for the Leases (as defined below).

  • Construction Work The regulation at 41 C.F.R. § 60-1.3 defines “construction work” as the construction, rehabilitation, alteration, conversion, extension, demolition or repair of buildings, highways, or other changes or improvements to real property, including facilities providing utility services. The term also includes the supervision, inspection, and other onsite functions incidental to the actual construction.

  • Construction, Etc Each covenant contained herein shall be construed (absent express provision to the contrary) as being independent of each other covenant contained herein, so that compliance with any one covenant shall not (absent such an express contrary provision) be deemed to excuse compliance with any other covenant. Where any provision herein refers to action to be taken by any Person, or which such Person is prohibited from taking, such provision shall be applicable whether such action is taken directly or indirectly by such Person. For the avoidance of doubt, all Schedules and Exhibits attached to this Agreement shall be deemed to be a part hereof.

  • Construction Contracts Item A: Enter the total dollar amount of all contacts awarded on the project/ program. Item B: Enter the total dollar amount of contracts connected with this project/program that were awarded to Section 3 businesses.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!