Construction Staging and Storage Sample Clauses

Construction Staging and Storage. Area Site Plan Submittal to OE/AAA: Xxxxxx will prepare a final FAA 7460‐1 Site Exhibit that illustrates the Contractor’s Staging and Storage Area, Haul Route, anticipated construction equipment heights, and location of construction equipment.
Sample 1Sample 2
AutoNDA by SimpleDocs
Construction Staging and Storage. The Contractor is responsible for the staging and storage of materials. The County will provide no space outside of LOD shown on the approved plan. The Contractor is responsible for securing all land and facilities necessary for construction staging, including but not limited to the protection of materials, disposal of waste, parking, and temporary utilities at no additional cost to the county. The Contractor shall secure the work zone areas at all times.
Sample 1

Related to Construction Staging and Storage

  • Construction Staking Contractor shall avoid careless or negligent damage to construction stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes necessary to construc- tion. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under E.2.1.8. When A.7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construction stakes. Time for setting construction stakes may be modified by written agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contrac- tor’s clearing and other construction activity to proceed without hindrance or delay, provided Contractor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto. Should Forest Service be unable to perform construction staking in such reasonable period, upon written agree- ment, Contractor shall assume the responsibility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:

  • Construction Safety Prior to contract award, the successful bidder must provide a Certificate of Recognition or Letter of Good Standing issued by an occupational health and safety organization approved by the Workers’ Compensation Board of Nova Scotia.

  • Staging In addition to the staging categories listed in paragraph 1 of Annex 2-A, this Schedule contains staging categories 20-A, 20-B, PR-1 and PR-130:

  • Construction Sequencing In general, the sequence of the proposed dates of Initial Operation of Interconnection Customers seeking interconnection to the Transmission System will determine the sequence of construction of Network Upgrades.

  • Construction Standards The Subrecipient and Developer shall ensure that all Approved Projects comply with the following requirements:

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Commissioning Commissioning tests of the Interconnection Customer's installed equipment shall be performed pursuant to applicable codes and standards. If the Interconnection Customer is not proceeding under Section 2.3.2, the Utility must be given at least ten (10) Business Days written notice, or as otherwise mutually agreed to by the Parties, of the tests and may be present to witness the commissioning tests.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.

Time is Money Join Law Insider Premium to draft better contracts faster.