Construction Staking Contractor shall avoid careless or negligent damage to construction stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes necessary to construc- tion. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under E.2.1.8. When A.7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construction stakes. Time for setting construction stakes may be modified by written agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contrac- tor’s clearing and other construction activity to proceed without hindrance or delay, provided Contractor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto. Should Forest Service be unable to perform construction staking in such reasonable period, upon written agree- ment, Contractor shall assume the responsibility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Drawings and Specifications at the Project Site The Contractor shall keep at the Site at least one copy of the Contract Documents and Change Orders, all in good order and available to the Design Professional and to his representatives.
Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.
Construction Standards The Subrecipient and Developer shall ensure that all Approved Projects comply with the following requirements:
EU SURVEY 5.1. The participant shall complete and submit the online EU Survey after the mobility abroad within 30 calendar days upon receipt of the invitation to complete it.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Survey Buyer may obtain a survey of the Property before the Closing to assure that there are no defects, encroachments, overlaps, boundary line or acreage disputes, or other such matters, that would be disclosed by a survey ("Survey Problems"). The cost of the survey shall be paid by the Buyer. Not later than business days prior to the Closing, Buyer shall notify Seller of any Survey Problems which shall be deemed to be a defect in the title to the Property. Seller shall be required to remedy such defects within business days and prior to the Closing. If Seller does not or cannot remedy any such defect(s), Buyer shall have the option of canceling this Agreement, in which case the Xxxxxxx Money shall be returned to Buyer.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
