Consultants and Staff Sample Clauses

Consultants and Staff. District and Architect agree that the professional services under this Agreement require adequate staffing and continuity of qualified people. All key staff listed below have been approved by District and Architect and may not be changed without prior written approval of the District except when such staff cease to work for Architect. If District finds the performance of an approved individual not acceptable, District shall notify Architect who shall then take necessary corrective action. If unable to correct performance to District’s satisfaction, Architect shall make appropriate staffing changes acceptable to the District. (1) All engineers and experts and consultants employed by Architect not listed herein shall be approved in writing in advance by District prior to their engagement. Architect shall supervise and shall be responsible for the work of consultants hired by Architect. Architect shall confer and cooperate with landscape architects, educational planners, and other professional consultants employed by District. (2) Architect shall require each engineer and consultant listed above, prior to commencing any services relating to the Project, to provide District with evidence that each such engineer or consultant has in effect a policy of comprehensive general liability insurance, with the same limits, endorsements and requirements as specified in Paragraph 9 of this Agreement. (3) Architect, as part of the Basic Services, shall furnish, at Architect’s own expense, all draftsmen and clerical personnel necessary to perform the services described herein. (4) Architect shall promptly notify District of reassignment or replacement of engineers, consultants and experts specified above. Architect shall also notify District of staff changes of all other key personnel working on the Project.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Consultants and Staff. DISTRICT and ARCHITECT agree that the professional services under this Agreement require adequate staffing and continuity of qualified people. All key staff listed below have been approved by DISTRICT and ARCHITECT and may not be changed without prior approval except for an individual leaving the firms employ. If DISTRICT finds the performance of an approved individual not acceptable, DISTRICT will notify ARCHITECT who will take necessary corrective action. If unable to correct performance to DISTRICT’s satisfaction, ARCHITECT will make appropriate staffing changes acceptable to DISTRICT. Position Individual Firm Principal in charge Project Architect Principal Engineer, Structural Project Engineer, Structural Principal Engineer, Civil Project Engineer, Civil Principal Engineer, Mechanical Project Engineer, Mechanical Principal Engineer, Electrical Project Engineer, Electrical i. All engineers and experts and consultants employed by ARCHITECT not listed herein shall be approved in advance by DISTRICT prior to their engagement. ARCHITECT shall confer and cooperate with landscape architects, educational planners, and other professional consultants employed by DISTRICT. ii. ARCHITECT shall cause each engineer and consultant listed above, before the time such engineer or consultant shall commence any services relating to the Project, to provide DISTRICT with evidence that each such engineer and consultant has in effect a policy of comprehensive general liability insurance, which shall have the same limits, endorsements and requirements as specified in Paragraph 9 of this Agreement, and, in addition, is covered by a policy of professional liability insurance in a minimum amount of $1,000,000.00 with an insurance carrier satisfactory to DISTRICT. iii. ARCHITECT shall promptly notify DISTRICT of reassignment or replacement of engineers, consultants and experts specified above. ARCHITECT shall also notify DISTRICT of staff changes of all other key personnel working on the Project. i. ARCHITECT shall promptly notify DISTRICT of any significant defect that an ARCHITECT exercising reasonable professional judgment in the course of maintaining familiarity with the construction work would detect in materials, equipment, or workmanship which comes to ARCHITECT'S attention and of any known or observed default by the contractor in the orderly and timely progression or prosecution of the work. j ARCHITECT will endeavor to secure compliance by contractors with the contract re...
Sample 1
Consultants and Staff. District and Architect agree that the professional services under this agreement require continuity of qualified people. All key staff listed below have been approved by District and Architect and may not be changed without prior approval except for an individual leaving the firms employ. If the District finds the performance of an approved individual not acceptable, District will notify Architect who will take necessary corrective action. If unable to correct performance to District’s satisfaction, Architect will make appropriate staffing changes acceptable to District.
Sample 1

Related to Consultants and Staff

  • Conduct of Employees and Staff Contractor shall ensure that all of Contractor’s employees and Staff provided under the Contract shall adhere to the standards of conduct prescribed in the Customer’s personnel policy and procedure guidelines, particularly rules of conduct, security procedures, and any other applicable rules, regulations, policies, and procedures of the Customer, including but not limited to Rule Chapter 33-208, Florida Administrative Code. The Contractor shall ensure that all Staff and employees wear attire suitable for the position, either a standard uniform or business casual dress, identified by the Customer.

  • Consultants Any and all consultant(s), sub-consultant(s), subcontractor(s), or agent(s) to the Architect.

  • Architects, Consultants and Contractors Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.

  • Consultants and Employees Bound Recipient agrees to disclose the Confidential Information to any agents, affiliates, directors, officers or any other employees (collectively, the “Employees”) solely on a need-to-know basis and represents that such Employees have signed appropriate non-disclosure agreements or taken appropriate measures imposing on such Employees a duty to third parties (1) to hold any third party proprietary information received by such Employees in the strictest confidence, (2) not to disclose such third party Confidential Information to any other third party, and (3) not to use such Confidential Information for the benefit of anyone other than to whom it belongs, without the prior express written authorization of the Company.

  • Subconsultants Whichever of the following is marked applies to this Approved Service Order: The Consultant can not use any subconsultants. The Consultant can use the following subconsultants to assist in providing the required services and deliverables: 2. 3.

  • Employees and Subcontractors It is understood that, from time to time, it may become necessary for the Contractor to replace an individual working as an employee or subcontractor of the Contractor. All such removals or replacements shall be subject to Owner’s prior approval. Owner reserves the right to approve a replacement, which approval shall not be unreasonably withheld, or terminate the Work, either partially or in its entirety without further obligation to the Contractor thereunder other than to remit payment for the Work rendered up to the termination date. Contractor agrees that Owner may, at any time, with cause, require Contractor to remove an individual from the performance of the Work. An election by Owner of any of its rights under this Section 19 shall not affect the Contractor’s responsibilities, liabilities or warranties under this Agreement.

  • Employees and Independent Contractors Party agrees that it shall comply with the laws of the State of Vermont with respect to the appropriate classification of its workers and service providers as “employees” and “independent contractors” for all purposes, to include for purposes related to unemployment compensation insurance and workers compensation coverage, and proper payment and reporting of wages. Party agrees to ensure that all of its subcontractors or sub-grantees also remain in legal compliance as to the appropriate classification of “workers” and “independent contractors” relating to unemployment compensation insurance and workers compensation coverage, and proper payment and reporting of wages. Party will on request provide to the Agency of Human Services information pertaining to the classification of its employees to include the basis for the classification. Failure to comply with these obligations may result in termination of this Agreement.

  • Sub-Consultants All sub-consultants shall comply with each and every insurance provision of this Section 3.

  • Individual Consultants Services for assignments that meet the requirements set forth in the first sentence of paragraph 5.1 of the Consultant Guidelines may be procured under contracts awarded to individual consultants in accordance with the provisions of paragraphs 5.2 through 5.3 of the Consultant Guidelines. Under the circumstances described in paragraph 5.4 of the Consultant Guidelines, such contracts may be awarded to individual consultants on a sole-source basis.

  • Consultant’s Representative Consultant hereby designates XXXXXX, or his or her designee, to act as its representative for the performance of this Agreement (“Consultant’s Representative”). Consultant’s Representative shall have full authority to represent and act on behalf of the Consultant for all purposes under this Agreement. The Consultant’s Representative shall supervise and direct the Services, using their best skill and attention, and shall be responsible for all means, methods, techniques, sequences, and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!