MANAGEMENT OF EVALUATION OUTCOMES 12.1 Where the Employer is, any time during the Employee’s employment, not satisfied with the Employee’s performance with respect to any matter dealt with in this Agreement, the Employer will give notice to the Employee to attend a meeting; 12.2 The Employee will have the opportunity at the meeting to satisfy the Employer of the measures being taken to ensure that his performance becomes satisfactory and any programme, including any dates, for implementing these measures; 12.3 Where there is a dispute or difference as to the performance of the Employee under this Agreement, the Parties will confer with a view to resolving the dispute or difference; and 12.4 In the case of unacceptable performance, the Employer shall – 12.4.1 Provide systematic remedial or developmental support to assist the Employee to improve his performance; and 12.4.2 After appropriate performance counselling and having provided the necessary guidance and/or support as well as reasonable time for improvement in performance, the Employer may consider steps to terminate the contract of employment of the Employee on grounds of unfitness or incapacity to carry out his or her duties.
Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout
Management and Control Systems Grantee will: 1. maintain an appropriate contract administration system to ensure that all terms, conditions, and specifications are met during the term of the contract through the completion of the closeout procedures. 2. develop, implement, and maintain financial management and control systems that meet or exceed the requirements of Uniform Statewide Accounting System (UGMS). Those requirements and procedures include, at a minimum, the following: i. Financial planning, including the development of budgets that adequately reflect all functions and resources necessary to carry out authorized activities and the adequate determination of costs; ii. Financial management systems that include accurate accounting records that are accessible and identify the source and application of funds provided under each Contract of this Contract, and original source documentation substantiating that costs are specifically and solely allocable to a Contract and its Contract and are traceable from the transaction to the general ledger; iii. Effective internal and budgetary controls; iv. Comparison of actual costs to budget; determination of reasonableness, allowableness, and allocability of costs; v. Timely and appropriate audits and resolution of any findings; vi. Billing and collection policies; and vii. Mechanism capable of billing and making reasonable efforts to collect from clients and third parties.
Portfolio Management Services As manager of the assets of the Fund, you shall provide continuing investment management of the assets of the Fund in accordance with the investment objectives, policies and restrictions set forth in the Prospectus and SAI; the applicable provisions of the 1940 Act and the Internal Revenue Code of 1986, as amended, (the "Code") relating to regulated investment companies and all rules and regulations thereunder; and all other applicable federal and state laws and regulations of which you have knowledge; subject always to policies and instructions adopted by the Trust's Board of Trustees. In connection therewith, you shall use reasonable efforts to manage the Fund so that it will qualify as a regulated investment company under Subchapter M of the Code and regulations issued thereunder. The Fund shall have the benefit of the investment analysis and research, the review of current economic conditions and trends and the consideration of long-range investment policy generally available to your investment advisory clients. In managing the Fund in accordance with the requirements set forth in this section 2, you shall be entitled to receive and act upon advice of counsel to the Trust. You shall also make available to the Trust promptly upon request all of the Fund's investment records and ledgers as are necessary to assist the Trust in complying with the requirements of the 1940 Act and other applicable laws. To the extent required by law, you shall furnish to regulatory authorities having the requisite authority any information or reports in connection with the services provided pursuant to this Agreement which may be requested in order to ascertain whether the operations of the Trust are being conducted in a manner consistent with applicable laws and regulations. You shall determine the securities, instruments, investments, currencies, repurchase agreements, futures, options and other contracts relating to investments to be purchased, sold or entered into by the Fund and place orders with broker-dealers, foreign currency dealers, futures commission merchants or others pursuant to your determinations and all in accordance with Fund policies as expressed in the Registration Statement. You shall determine what portion of the Fund's portfolio shall be invested in securities and other assets and what portion, if any, should be held uninvested. You shall furnish to the Trust's Board of Trustees periodic reports on the investment performance of the Fund and on the performance of your obligations pursuant to this Agreement, and you shall supply such additional reports and information as the Trust's officers or Board of Trustees shall reasonably request.
RESERVATIONS TO MANAGEMENT 6.01 The Union recognizes the right of the Employer to direct the workforce, to promote, demote, transfer or discharge. 6.02 The Union further recognizes the right of the Employer to operate and manage its business in all respects. 6.03 The Employer also reserves the right to supplement and alter, from time to time, reasonable rules and regulations to be observed by the employees. 6.04 Such management rights shall be exercised in a manner which shall not be inconsistent with the terms of the Agreement.
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Contract Management To ensure full performance of the Contract and compliance with applicable law, the System Agency may take actions including: a. Suspending all or part of the Contract; b. Requiring the Grantee to take specific corrective actions in order to remain in compliance with term of the Contract; c. Recouping payments made to the Grantee found to be in error; d. Suspending, limiting, or placing conditions on the continued performance of the Project; e. Imposing any other remedies authorized under this Contract; and f. Imposing any other remedies, sanctions or penalties permitted by federal or state statute, law, regulation, or rule.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
SITE MANAGEMENT We reserve the right, but not the obligation, to: (1) monitor the Site for violations of these Terms of Use; (2) take appropriate legal action against anyone who, in our sole discretion, violates the law or these Terms of Use, including without limitation, reporting such user to law enforcement authorities; (3) in our sole discretion and without limitation, refuse, restrict access to, limit the availability of, or disable (to the extent technologically feasible) any of your Contributions or any portion thereof; (4) in our sole discretion and without limitation, notice, or liability, to remove from the Site or otherwise disable all files and content that are excessive in size or are in any way burdensome to our systems; and (5) otherwise manage the Site in a manner designed to protect our rights and property and to facilitate the proper functioning of the Site.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.