Contractor’s Right to Suspend Performance Sample Clauses

Contractor’s Right to Suspend Performance. In the event of a breach of this Agreement by County, including without limitation, County being more than 30 days past due in payment of any applicable undisputed fees, Contractor may, without prejudice to any other right or remedy available to Contractor, suspend performance under this Agreement until the breach is cured, i.e., County pays all outstanding dues and balances in full. Neither CONTRACTOR nor COUNTY shall be liable, nor may cancel this contract for default, when delays arise out of causes beyond the control of CONTRACTOR or COUNTY. Such causes may include but are not restricted to acts of God, acts of COUNTY in sovereign capacity, fires, floods, lightning strikes, epidemics, quarantine restrictions, strikes, freight embargoes, wars, civil disturbances, work stoppage, power failures, laws, regulations, ordinances, acts or orders of any governmental agency or official thereof, and unusually severe weather. In every case, the delay must be beyond the control of the claiming party. If CONTRACTOR is delayed in its performance as a result of the above causes, COUNTY, shall upon written request of CONTRACTOR, agree to equitably adjust the provisions of this contract, including price and delivery, as may be affected by such delay. However, this provision shall not be interpreted to limit COUNTY’S right to terminate for convenience.
Sample 1
AutoNDA by SimpleDocs
Contractor’s Right to Suspend Performance. Contractor will have the right to suspend work if Owner fails to make any reasonably undisputed payment to Contractor within ten (10) days of the date such payment is due, and such suspension shall entitle Contractor to equitable adjustment(s) to the Contract Price and Project Schedule.
Sample 1

Related to Contractor’s Right to Suspend Performance

  • Continuity of Service and Performance Unless otherwise agreed in writing, the Parties shall continue to provide service and honor all other commitments under this Agreement during the course of a Dispute with respect to all matters not subject to such Dispute.

  • Payment and Performance Borrower will pay all amounts due under the Loan Documents in accordance with the terms thereof and will observe, perform and comply with every covenant, term and condition expressed or implied in the Loan Documents. Borrower will cause each other Restricted Person to observe, perform and comply with every such term, covenant and condition.

  • Capacity and Performance (a) During the term hereof, the Executive shall serve the Company as its Vice President and Chief Operating Officer. In addition, and without further compensation, the Executive shall serve as a director of the Company, if so elected by the stockholders of the Company, and shall serve as a director of one or more of the Company’s Affiliates if so elected from time to time.

  • PAYMENT AND PERFORMANCE OF LIABILITIES The Borrowers shall pay each payment Liability when due (or when demanded, if payable on demand) and shall promptly, punctually, and faithfully perform each other Liability.

  • Excused Performance 6.1 Notwithstanding the occurrence of a Force Majeure Event, in which case Clause 17 will govern, BT will not be liable for any failure or delay to perform any of its obligations under this Agreement (including any of its obligations to meet any Service Levels) to the extent that BT’s failure or delay in performing arises as a result of:

  • Duties and Performance From time to time during the term of this Agreement, Consultant shall provide such advisory services relating to the Company's financial status and capital structure (the "SERVICES") to Company as Consultant and Company shall agree. In connection with the Services, Consultant may develop and communicate to Company certain business opportunities with entities known to Consultant; the Services may include various types of arrangements, including direct investment into Company.

  • Execution and Performance of Agreement The performance of this Agreement by Purchaser will not result in a default of any other agreement to which Purchaser is a party. Purchaser has the authority to enter into this Agreement.

  • Guaranty of Payment and Performance Guarantor’s obligations under this Guaranty constitute an unconditional guaranty of payment and performance and not merely a guaranty of collection.

  • Execution, Delivery and Performance The execution, delivery and performance of this Agreement and the documents or instruments required under this Agreement will not violate any provision of any existing law or regulation binding on the Manager, or any order, judgment, award or decree of any court, arbitrator or governmental authority binding on the Manager, or the governing instruments of, or any securities issued by, the Manager or of any mortgage, indenture, lease, contract or other agreement, instrument or undertaking to which the Manager is a party or by which the Manager or any of its assets may be bound, the violation of which would have a material adverse effect on the business operations, assets or financial condition of the Manager and its subsidiaries, taken as a whole, and will not result in, or require, the creation or imposition of any lien on any of its property, assets or revenues pursuant to the provisions of any such mortgage indenture, lease, contract or other agreement, instrument or undertaking.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!