Warranty Obligations
(a) Project Co represents, warrants and covenants that:
(i) the Works shall conform to the requirements of this Project Agreement, Good Industry Practice, Applicable Law and all professional engineering principles generally accepted as standards of the industry in the Province of Ontario;
(ii) the Works shall be free of defects, including design defects, errors and omissions; and
(iii) materials and equipment shall be of good quality and in compliance with this Project Agreement.
(b) During the Warranty Period and subject to Section 11.15(c), Project Co shall promptly, at its sole cost and expense, correct and Make Good all Construction Defects arising in respect of the Works. For greater certainty, Project Co is required to correct and Make Good Construction Defects related to any Product during the applicable Warranty Period despite Project Co having obtained on Contracting Authority’s behalf industry- standard or other equipment warranties in accordance with Section 11.15(f). For all work to correct Construction Defects, the applicable Warranty Period shall be extended for a further two years from the date of the last work completed in respect of such corrective Works. For clarity, any extension of a Warranty Period for the purposes of a correction shall only apply to the relevant Construction Defect and not the Works as a whole.
(c) In addition to the obligation to correct and Make Good Construction Defects during the Warranty Period, Project Co shall at its expense correct and Make Good any Construction Defects that could not reasonably have been ascertained by a competent person in accordance with Good Industry Practice during a visual inspection of the Works (“Construction Latent Defect”), provided Contracting Authority gives Project Co written Notice of the Construction Latent Defect within the time frame applicable to such Construction Latent Defect pursuant to the Limitations Act, 2002 (Ontario).
(d) The warranties described in this Section 11.15 shall cover labour and material, including, the costs of removal and replacement of covering materials. The warranties shall not limit extended warranties on any Product or item of equipment called for elsewhere in the Output Specifications or otherwise provided by any manufacturer of such Product or equipment.
(e) If Project Co fails to correct and Make Good any Construction Defects or Construction Latent Defects in accordance with Sections 11.15(b) and 11.15(c) and in the time period specified in Section 11.16(a) or Section 11.16(b), as applicable, without prejudice to any other right or remedy Contracting Authority may have, Contracting Authority may correct such Construction Defects or Construction Latent Defects at Project Co’s sole cost and expense.
(f) Project Co shall obtain warranties from the manufacturers of each of the Products for the duration(s) and in accordance with the applicable requirements specified in the Output Specifications in the name of and to the benefit of both Project Co and Contracting Authority. Where, in respect of a Product warranty, the Output Specifications do not specify a specific duration and/or other requirements, Project Co shall obtain industry-standard warranties from the applicable manufacturers in the name of and to the benefit of Project Co and Contracting Authority which shall extend no less than two years from the Substantial Completion Date. Each Product warranty shall be issued by the applicable manufacturer and delivered to Project Co no later than 30 days prior to the Substantial Completion Date. Project Co shall ensure that each Product warranty, including any Product warranty extended under this Section 11.15(f), is fully assigned to Contracting Authority, at no cost or expense to Contracting Authority, at the end of the Warranty Period, as such Warranty Period may be extended in accordance with Section 11.15(b).
Assigned Contracts Each Credit Party will secure all consents and approvals necessary or appropriate for the assignment to or for the benefit of Agent of any Assigned Contract and to enforce the security interests granted hereunder. Each Credit Party shall fully perform all of its obligations under each of its Assigned Contracts, and shall enforce all of its rights and remedies thereunder, in each case, as it deems appropriate in its business judgment. Such Credit Party shall notify Agent in writing, promptly after such Credit Party becomes aware thereof, of any event or fact which could give rise to a material claim by it for indemnification under any of its Assigned Contracts. If an Event of Default then exists, Agent may, and at the direction of Required Lenders shall, directly enforce such right in its own or such Credit Party’s name and may enter into such settlements or other agreements with respect thereto as Agent shall determine. In any suit, proceeding or action brought by Agent under any Assigned Contract for any sum owing thereunder or to enforce any provision thereof, the Credit Parities shall indemnify and hold Agent and Lenders harmless from and against all expense, loss or damage suffered by reason of any defense, setoff, counterclaims, recoupment, or reduction of liability whatsoever of the obligor thereunder arising out of a breach by such Credit Party of any obligation thereunder or arising out of any other agreement, indebtedness or liability at any time owing from the Credit Parties to or in favor of such obligor or its successors, except for such expenses, damages or losses resulting from Agent’s or any Lender’s gross negligence or willful misconduct. All such obligations of the Credit Parties shall be and remain enforceable only against the Credit Parties and shall not be enforceable against Agent or Lender. Notwithstanding any provision hereof to the contrary, the Credit Parties shall at all times remain liable to observe and perform all of its duties and obligations under its Assigned Contracts, and Agent’s exercise of any of its rights with respect to the Collateral shall not release the Credit Parties from any of such duties and obligations. Neither Agent nor any Lender shall be obligated to perform or fulfill any of any Credit Party’s duties or obligations under its Assigned Contracts or to make any payment thereunder, or to make any inquiry as to the nature or sufficiency of any payment or property received by it thereunder or the sufficiency of performance by any party thereunder, or to present or file any claim, or to take any action to collect or enforce any performance, any payment of any amounts, or any delivery of any property.
Contracts and Agreements The agreements and documents described in the Registration Statement and the Prospectus conform in all material respects to the descriptions thereof contained therein and there are no agreements or other documents required by the Securities Act to be described in the Registration Statement and the Prospectus or to be filed with the Commission as exhibits to the Registration Statement, that have not been so described or filed. Each agreement or other instrument (however characterized or described) to which the Company is a party or by which it is or may be bound or affected and (i) that is referred to in the Registration Statement and the Prospectus, or (ii) is material to the Company’s business, has been duly authorized and validly executed by the Company, is in full force and effect in all material respects and is enforceable against the Company and, to the Company’s knowledge, the other parties thereto, in accordance with its terms, except (x) as such enforceability may be limited by bankruptcy, insolvency, reorganization or similar laws affecting creditors’ rights generally, (y) as enforceability of any indemnification or contribution provision may be limited under the federal and state securities laws, and (z) that the remedy of specific performance and injunctive and other forms of equitable relief may be subject to the equitable defenses and to the discretion of the court before which any proceeding therefor may be brought. None of such agreements or instruments has been assigned by the Company, and neither the Company nor, to the Company’s knowledge, any other party is in default thereunder and, to the Company’s knowledge, no event has occurred that, with the lapse of time or the giving of notice, or both, would constitute a default thereunder. To the best of the Company’s knowledge, performance by the Company of the material provisions of such agreements or instruments will not result in a violation of any existing applicable law, rule, regulation, judgment, order or decree of any governmental agency or court, domestic or foreign, having jurisdiction over the Company or any of its assets or businesses (each, a “Governmental Entity”), including, without limitation, those relating to environmental laws and regulations.
Covered Contracts and Contractors If the Contract exceeds $100,000 and the Contractor employed more than 40 full-time employees on a single working day during the previous 12 months in Minnesota or in the state where it has its principle place of business, then the Contractor must comply with the requirements of Minnesota Statute § 363A.36 and Minnesota Rule Parts 5000.3400-5000.3600. A Contractor covered by Minnesota Statute § 363A.36 because it employed more than 40 full-time employees in another state and does not have a certificate of compliance, must certify that it is in compliance with federal affirmative action requirements.
Assumed Contracts (a) Other than the Assumed Contracts, no existing contracts with Seller shall be assumed by Purchaser, without specific, individual, written consent by Purchaser.
(b) Seller shall provide Purchaser a list of all existing contracts on Schedule 3.9(b). Except for the Assumed Contracts, Seller is not a party to or otherwise bound by the terms of any material contract, agreement or obligation, written or oral, affecting the Business or the Assets. Seller shall separately identify each Assumed Contract (i) pursuant to which any other party is granted “most favored party” rights of any type or scope, or containing any non-solicitation or non-competition covenants or other restrictions relating to the Business or that limits the freedom of Seller to engage or participate, or compete with any other Person, in any line of business, market or geographic area, or to make use of any Transferred Intellectual Property, (ii) that is an IP Agreement, (iii) that imposes on Seller payment obligations (contingent or otherwise) in excess of $5,000 per annum, (iv) that provides for payments to Seller in excess of $5,000 per annum, (v) that constitutes a partnership or joint venture agreement, (vi) that evidences outstanding Indebtedness which constitutes an Asset and (vii) that is a Lease.
(c) Assumed Contracts (if any) are valid, binding and in full force and effect and enforceable by Seller prior to Closing and by Purchaser upon and after Closing.. Neither Seller, nor, to Seller’s Knowledge, any other party, is in material breach, violation of, or default under, and to the Knowledge of Seller, no event has occurred which, with the lapse of time or the giving of notice, or both, is reasonably likely to result in a breach or violation by Seller or such other party of, or default under, any Assumed Contract, and there are no existing disputes or claims of default relating thereto, or any facts or conditions Known to Seller which, if continued, will result in a material default or claim of default thereunder. Seller has not received any written or, to the Knowledge of Seller, oral notice of the intention of any party to terminate, cancel, amend or not renew any Assumed Contract. Except as set forth in Section 1.7, no consents are necessary for the effective assignment to and assumption by Purchaser of any of the Assumed Contracts including but not limited to the lease on the Premises. Seller has furnished or made available to Purchaser true and complete copies of all Assumed Contracts and descriptions of all material terms of Assumed Contracts that are not in writing, including any amendments, waivers or other changes thereto.
Seller Contracts All contracts and agreements, other than ---------------- Governmental Permits and those relating to Real Property, pertaining to the ownership, operation and maintenance of the Assets or the Business or used or held for use in the Business, as described on SCHEDULE 5.6 or, in the case of contracts and agreements relating to Real Property, on SCHEDULE 5.7.
Contracts and Leases Schedule 4.10 sets forth a true and complete list of all Leases and executory Contracts of the Company that are material to the Business, and Sellers have delivered to Buyer true and complete copies of all such Leases and Contracts, each as amended as of the Agreement Date (the “Material Contracts”). Subject to receipt of the Necessary Consents and compliance with Section 6.10 and subject to the entry of the Sale Order, and any ancillary orders of the Bankruptcy Court pertaining to assumption and assignment of Contracts (a) each of the Material Contracts is in full force and effect and constitutes a valid and binding obligation of the Company or Sellers, and, to the Knowledge of Sellers, each other party thereto, and (b) except as a result of the commencement of the Bankruptcy Cases, the Company or Sellers are not in breach or default in any material respect under any of the Material Contracts and, to the Knowledge of Sellers, the other parties to such Contracts are not in breach or default in any material respect thereunder (and in each such case, to the Knowledge of Sellers, no event exists that with the passage of time or the giving of notice would constitute such material breach or default in any material respect, result in a loss of material rights, result in the payment of any damages or penalties or result in the creation of any Liens thereunder or pursuant thereto other than Permitted Liens); except (i) for those defaults that will be cured in accordance with the Sale Order, are not required to be cured pursuant to section 365(b)(1)(A) of the Bankruptcy Code, or waived in accordance with section 365 of the Bankruptcy Code, or (ii) to the extent such breach or default would not reasonably be expected to have a Seller Material Adverse Effect. Except for filings in the Chapter 11 Cases, to Sellers’ Knowledge, none of the Material Contracts have been cancelled or otherwise terminated by the Company or Sellers, and neither the Company nor Sellers have not delivered any written notice to any counterparty to such Material Contract regarding any such cancellation or termination by the Company or Sellers.
Guaranty Obligations Unless otherwise specified, the amount of any Guaranty Obligation shall be the lesser of the principal amount of the obligations guaranteed and still outstanding and the maximum amount for which the guaranteeing Person may be liable pursuant to the terms of the instrument embodying such Guaranty Obligation.
SUB-CONTRACTS (a) The Administrator may sub-contract or delegate the performance of all or any of its powers and obligations under this Agreement, provided that (but subject to Clause 3.2(b) herein):
(i) the prior written consent of the Mortgages Trustee and Funding to the proposed arrangement (including, if Funding considers it necessary after consulting with the Security Trustee, approving any contract which sets out the terms on which such arrangements are to be made) has been obtained, the Security Trustee has been consulted and notification has been given to each of the Rating Agencies;
(ii) where the arrangements involve the custody or control of any Mortgage Loan Files and/or Title Deeds relating to the Mortgage Portfolio for the purpose of performing any delegated Services, the sub-contractor or delegate has executed an acknowledgement in writing acceptable to Funding and the Security Trustee to the effect that any such Mortgage Loan Files and/or Title Deeds are and will be held to the order of the Mortgages Trustee (as trustee for the Beneficiaries);
(iii) where the arrangements involve or may involve the receipt by the sub-contractor or delegate of monies belonging to the Beneficiaries which, in accordance with this Agreement, are to be paid into the relevant Collection Account, the sub-contractor or delegate has executed a declaration in writing acceptable to the Beneficiaries that any such monies held by it or to its order are held on trust for the Beneficiaries and will be paid forthwith into the relevant Collection Account in accordance with the terms of the Mortgages Trust Deed;
(iv) any such sub-contractor or delegate has executed a written waiver of any Security Interest arising in connection with such delegated Services (to the extent that such Security Interest relates to the Mortgage Portfolio or any amount referred to in (iii) above); and
(v) neither the Mortgages Trustee, the Security Trustee nor the Beneficiaries shall have any liability for any costs, charges or expenses payable to or incurred by such sub-contractor or delegate or arising from the entering into, the continuance or the termination of any such arrangement.
(b) The provisos to Clause 3.2(a) (i), (ii) and (iii) herein shall not apply:
(i) to the engagement by the Administrator of:
(1) any receiver, solicitor, insurance broker, valuer, surveyor, accountant, estate agent, insolvency practitioner, auctioneer, bailiff, debt counsellor, tracing agent, property management agent, licensed or qualified conveyancer or other professional adviser acting as such; or
(2) any locksmith, builder or other contractor acting as such in relation to a Mortgaged Property, in any such case being a person or persons whom the Administrator would be willing to appoint in respect of its own mortgages in connection with the performance by the Administrator of any of its obligations or functions or in connection with the exercise of its powers under this Agreement; or
(ii) to any delegation to any wholly-owned subsidiary of the Seller from time to time.
(c) The Mortgages Trustee and/or Funding and the Security Trustee may require the Administrator to assign to the Mortgages Trustee any rights which the Administrator may have against any sub-contractor or delegate arising from the performance of services by such person in association with any matter contemplated by this Agreement and the Administrator acknowledges that such rights assigned to the Mortgages Trustee will be exercised by the Mortgages Trustee as trustee for the Beneficiaries subject to the terms of the Mortgages Trust Deed.
(d) Notwithstanding any sub-contracting or delegation of the performance of the Administrator's obligations under this Agreement:
(i) the Administrator shall not thereby be released or discharged from any liability hereunder;
(ii) the Administrator shall remain responsible for the performance of the obligations of the Administrator under this Agreement;
(iii) the performance or non-performance or the manner of performance of any sub-contractor or delegate of any of the Services shall not affect the Administrator's obligations under this Agreement;
(iv) any breach in the performance of the Services by any sub-contractor or delegate shall, subject to the Administrator being entitled for a period of twenty (20) Business Days from receipt of notice of the breach to remedy such breach by any sub-contractor or delegate, be treated as a breach of this Agreement by the Administrator; and
(v) the Security Trustee shall have no liability for any act or omission of the sub-contractor or delegate and shall have no responsibility for monitoring or investigating the suitability of any such sub-contractor or delegate.
Third Party Contracts From the Effective Date through and including the Closing Date, Seller agrees to enter into only those third-party contracts which are necessary to carry out its obligations under Section 5.2, which shall be on market terms and cancellable on thirty (30) days written notice or less, without payment of any fee or penalty. Copies of all such contracts so entered into by Seller shall be promptly provided by Seller to Purchaser.
