Contracts; Change Orders; Public Releases. A. The Issuer shall, simultaneously with the delivery of the Series 2020 A Bonds or immediately thereafter, enter into written contracts for the immediate commencement of the design of the Design Project.
Contracts; Change Orders; Public Releases Sample Clauses
Related to Contracts; Change Orders; Public Releases
CONSTRUCTION/PUBLIC WORKS CONTRACTS In compliance with Article 8, Section 220 of the New York State Labor Law:
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:
CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to: request additional information reject Contract modifications remove Products from Contract modification requests request additional discounts for new or existing Products
PRIOR CONTRACTS SUPERSEDED This contract constitutes the sole agreement of the parties hereto for the services authorized herein and supersedes any prior understandings or written or oral contracts between the parties respecting the subject matter defined herein.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Violence Policies and Procedures The Employer agrees to have in place explicit policies and procedures to deal with violence. The policy will address the prevention of violence, the management of violent situations, provision of legal counsel and support to employees who have faced violence. The policies and procedures shall be part of the employee's health and safety policy and written copies shall be provided to each employee. Prior to implementing any changes to these policies, the employer agrees to consult with the Association.
ARBITRATION - SCHEDULING Timely complaints shall be submitted to and determined by an arbitrator. Each arbitration proceeding shall commence not earlier than ten (10) calendar days and not later than thirty (30) calendar days following the date of filing of the complaint.
Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
