CONVEYANCE AND POSSESSION OF SAID UNIT Sample Clauses

CONVEYANCE AND POSSESSION OF SAID UNIT. 7.1 Schedule for possession of the said Unit – The Promoter agrees and understands that timely delivery of possession of the Unit to the Allottee(s) and the Common Areas and Facilities of Said Project to the Maintenance Association, is the essence of the Agreement. The Promoter assures to handover possession of the said Unit along with ready and complete Common Areas and Facilities of Said Project with all specifications, amenities and facilities of the Said Project in place on or before 30/06/2020 unless there is delay or failure due to war, flood, drought, fire, cyclone earthquake or any other calamity caused by nature effecting the regular development of the Said Project (“Force Majeure”). If, however, the completion of Said Project is delayed due to the Force Majeure conditions then the Allottee(s) agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Said Unit and the Promoter shall not be liable to pay any penalty/interest/compensation during such Force Majeure condition, provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee(s) agrees and confirms that, in the event it becomes impossible for the Promoter to implement the said Project due to Force Majeure conditions, which shall be assessed by the Promoter, the Promoter shall inform the Allottee(s) about such impossibility along with notice of termination of one month and upon termination of this allotment, the Promoter shall refund to the Allottee(s) the entire amount received by the Promoter from the Allottee(s) with Interest (computed at the Interest Rate of 15% p.a.) within forty-five (45) days from the date on which termination became effective. After refund of the money paid by the Allottee(s), the Allottee(s) agrees that he/ she shall not have any rights, claims etc. against the Promoter and the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Sample 1Sample 2See All (9)
AutoNDA by SimpleDocs

Related to CONVEYANCE AND POSSESSION OF SAID UNIT

  • CONVEYANCE OF THE SAID APARTMENT The Promoter, on receipt of complete amount of the Price of the [Apartment/Plot] under the Agreement from the Allottee, shall execute a conveyance deed and convey the title of the [Apartment/Plot] together with proportionate indivisible share in the Common Areas within 3 (three) months from the issuance of the occupancy certificate*. However, in case the Allottee fails to deposit the stamp duty, registration charges and all other incidental and legal expenses etc. so demanded within the period mentioned in the demand letter, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till full and final settlement of all dues and stamp duty and registration charges to the Promoter is made by the Allottee. The Allottee shall be solely responsible and liable for compliance of the provisions of Indian Stamp Act, 1899 including any actions taken or deficiencies/ penalties imposed by the competent authority(ies).

  • PROCLAMATION OF SALE, CONDITIONS OF SALE AND MEMORANDUM OF SALE All contents in the Proclamation of Sale and this Conditions of Sale are to be read together and shall be part of the Memorandum of Sale.

  • Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2

  • Quiet Possession Upon Tenant’s paying the Basic Rental, Additional Rent and other sums provided hereunder and observing and performing all of the covenants, conditions and provisions on Tenant’s part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire Term hereof, subject to all of the provisions of this Lease.

  • BILL OF SALE This Bill of Sale is made and entered into as of this day of [ ], 2023 (the "Effective Date") by and between THE BOARD OF TRUSTEES, WESTERN NORTH CAROLINA CONFERENCE, UNITED METHODIST CHURCH, INC., a North Carolina non-profit corporation (the "Seller") and [ ], a North Carolina [ ] (the "Buyer”).

  • POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.

  • CONVEYANCE OF THE SAID PLOT The Promoter, on receipt of Total Price of the Plot as per Para 1.2 under the Agreement from the Allottee, shall execute a conveyance deed and convey the title of the Plot together within three months. However, in case the Allottee fails to deposit the stamp duty and/or registration charges and all other incidental and legal expenses towards execution of conveyance deed, so demanded within the period mentioned in the notice, the Allottee authorizes the Promoter to withhold registration of the conveyance deed in his/her favour till payment of stamp duty and registration charges to the Promoter is made by the Allottee.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!