Common Area Operating Expenses Lessee shall pay to Lessor during the term hereof, in addition to the Base Rent, Lessee's Share (as specified in Paragraph 1.6(b)) of all Common Area Operating Expenses, as hereinafter defined, during each calendar year of the term of this Lease, in accordance with the following provisions:
Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
Base Year The period beginning on 1 April of one year and ending on 31 March of the following year.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Operating Expenses The Lessor shall have no obligation to provide any services, perform any acts, or pay expenses, charges, obligations or costs of any kind whatsoever with respect to the Premises. The Lessee hereby agrees to pay one-hundred percent (100%) of any and all Operating Expenses as hereafter defined for the entire term of the Lease and any extensions thereof in accordance with specific provisions hereinafter set forth. The term “Operating Expenses” shall include all costs to the Lessor of operating and maintaining the Premises, and shall include, without limitation, real estate and personal property taxes and assessments, management fee(s), heating, air conditioning, HVAC, electricity, water, waste disposal, sewage, operating materials and supplies, service agreements and charges, lawn care, snow removal, restriping, repairs, repaving, cleaning and custodial, security, insurance, the cost of contesting the validity or applicability of any governmental acts which may affect operating expenses, and all other direct operating costs of operating and maintaining the Premises and related parking areas, unless expressly excluded from operating expenses.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Direct Expenses 1. Fees and expenses of its directors (except the fees of those directors who are deemed to be "interested persons" of the Fund as that term is defined in the Investment Company Act of 1940) and the meetings thereof;
Common Area Expenses In the event the demised premises are situated in a shopping center or in a commercial building in which there are common areas, Lessee agrees to pay his pro-rata share of maintenance, taxes, and insurance for the common area.
Tenant’s Share The term “Tenant’s Share” shall mean the percentage obtained by dividing Tenant’s Gross Leasable Area by the Building Gross Leasable Area, which as of the Effective Date is the percentage identified in Section G of the Summary.
Tenant’s Costs Whenever equipment or lighting (other than building standard lights or ordinary office equipment, including computers, copiers, lunch room refrigerators and microwaves) is used in the Premises by Tenant and such equipment or lighting affects the temperature otherwise normally maintained by the design of the Building’s air conditioning system, Landlord shall have the right to charge for supplementary air conditioning facilities in the Premises or otherwise modify the ventilating and air conditioning system serving the Premises; and the actual cost of such facilities, modifications and additional service (including an administrative fee) shall be paid by Tenant as Additional Rent within thirty (30) days of receipt of an invoice. Should Tenant desire any additional service beyond that described in Article 13.2, above, Landlord may, at Landlord’s option upon reasonable advance notice from Tenant to Landlord, (i) refuse to consent to such services or (ii) consent to such services upon such conditions as Landlord elects (including the requirements that submeters be installed at Tenant’s expense, that Tenant pay directly to the provider of such service (in the case of submetered services) or to Landlord, as Additional Rent within thirty (30) days of receipt of an invoice, Landlord’s additional expenses resulting therefrom, and that Tenant pay the cost of all alterations or additions made to accommodate such excess use, including the cost of a submeter and installation of the same). Landlord shall provide 40 tons of chilled water capacity to the Premises for Tenant’s server room and allow the installation of floor mounted air conditioning units and associated ductwork. The cost of installing connections and piping to new equipment shall be paid for out of the Cash Allowance. Tenant shall install metering to monitor use of the Building’s chilled water capacity and electricity. Installation may involve the addition of louvers to the North side of the building, and these louvers shall fit within the footprint of existing architectural louvers between structural grid lines 3 and 4, and shall be covered by the existing louver architectural skin as a visible surface.