JOC Pricing of Itemized List of RS Means Non-Prepriced Items No response The Vendor may download the optional Pricing of Itemized List of RS Means Non-Prepriced Items form from the attachment tab, fill in the requested information, and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files. Valid Reference Email addresses are REQUIRED on the spreadsheet. The vendor must download the References spreadsheet from the attachment tab, fill in the requested information and upload the completed spreadsheet. DO NOT UPLOAD encrypted or password protected files.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Definition of a Grievance A grievance is defined as a dispute or disagreement as to the interpretation or application of the specific terms and conditions of this AGREEMENT.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
Trustee Entitled to Assume Payments Not Prohibited in Absence of Notice The Company shall give prompt written notice to the Trustee of any fact known to the Company which would prohibit the making of any payment to or by the Trustee in respect of the Securities. Neither the Trustee nor the Paying Agent shall at any time be charged with the knowledge of the existence of any facts which would prohibit the making of any payment to or by the Trustee or the Paying Agent, unless and until the Trustee or Paying Agent shall have received written notice thereof from the Company or one or more holders of Senior Indebtedness or from any representative therefor; and, prior to the receipt of any such written notice, the Trustee or Paying Agent shall be entitled to assume conclusively that no such facts exist. Unless at least two (2) Business Days prior to the date on which by the terms of this Indenture any moneys are to be deposited by the Company with the Trustee or any Paying Agent (whether or not in trust) for any purpose (including, without limitation, the payment of the principal of or the interest on any Security), the Trustee or Paying Agent shall have received with respect to such moneys the notice provided for in the preceding sentence, the Trustee or Paying Agent shall have full power and authority to receive such moneys and to apply the same to the purpose for which they were received and shall not be affected by any notice to the contrary which may be received by it on or after such date. Nothing contained in this Section 12.09 or Section 12.03 shall limit the right of the holders of Senior Indebtedness to recover payments as contemplated by Section 12.02. The Trustee shall be entitled to rely on the delivery to it of a written notice by a person representing himself or itself to be a holder of such Senior Indebtedness (or a trustee on behalf of, or representative of, such holder) to establish that such notice has been given by a holder of such Senior Indebtedness or a trustee or representative on behalf of any such holder. In the event that the Trustee determines in good faith that further evidence is required with respect to the right of any person as a holder of Senior Indebtedness to participate in any payment or distribution pursuant to this Article XII, the Trustee may request such person to furnish evidence to the reasonable satisfaction of the Trustee as to the amount of Senior Indebtedness held by such person, the extent to which such person is entitled to participate in such payment or distribution and any other facts pertinent to the rights of such person under this Article XII, and if such evidence is not furnished, the Trustee may defer any payment which it may be required to make for the benefit of such person pursuant to the terms of this Indenture pending judicial determination as to the rights of such person to receive such payment. The Trustee shall not be deemed to owe any duty to the holders of Senior Indebtedness and shall not be liable to any such holders if the Trustee shall in good faith mistakenly pay over or distribute to Holders of Securities or to the Company or to any other person cash, property or securities to which any holders of Senior Indebtedness shall be entitled by virtue of this Article XII or otherwise. With respect to the holders of Senior Indebtedness, the Trustee undertakes to perform or to observe only such of its covenants or obligations as are specifically set forth in this Article XII and no implied covenants or obligations with respect to holders of Senior Indebtedness shall be read into this Indenture against the Trustee.
JOC Pricing of Itemized List of Means Non-Prepriced Items” based on the information herein. This Addendum is only to correct a misstatement on the original optional attachment entitled “PART 2 JOC Pricing of Itemized List of Means Non-Prepriced Items.” The attachment mistakenly provided for and discussed “Attribute 39.” Specifically, any erroneous reference to “Attribute 39” on the specified attachment should be considered immediately replaced with “the Attribute Question asking for Pricing for Markup of Non- Prepriced Items in RS Means Unit Price Book.” Please disregard any reference to Attribute 39 on this optional form and consider it to be referencing the Attribute Question asking for “Pricing for Markup of Non-Prepriced Items in RS Means Unit Price Book” instead.
Alternate or Supplemental Pricing Documents No response Optional. If when completing Pricing Form 1 & Pricing Form 2 you direct TIPS to view additional, alternate, or supplemental pricing documentation, you may upload that documentation.
