Landlord’s Work The Landlord will provide and carry out, in accordance with the provisions of the Lease, including, without limitation, this Schedule, at the Tenant’s expense, all equipment and work other than Tenant’s Work required to be provided in order to render the Premises complete and suitable to open for business (the “Landlord’s Work”) including, but not limited to the following: • Connecting all utilities including, power to building and distribution panels to the Premises, including the requirement to provide via separate metering. • Connecting water, including without limitation hot water, to greenhouse area and distribution water tank(s). • Installation of a storage cooler. • All concrete work around the greenhouse and drive-way to the compost hut and floor for compost piles as designed. • Installation of necessary or required ventilation fans. • Installation or replacement of lighting, including without limitation any required high upper grow lights. • Installation of hand wash stations in the Premises. • Gas heaters and controls. • Any repairs or refurbishing of outer panels, germination room walls. The Tenant’s consent (not to be unreasonably withheld, conditioned or delayed), shall be required prior to the commencement of the Landlord’s Work. The Landlord shall provide, in such detail as the Tenant may reasonably request, all material documentation relating to the Landlord’s Work, including without limitation, any proposed plans and drawings, proposed agreements with any contractors or subcontractors and estimated costs to complete the Landlord’s Work. Subject to receiving the Tenant’s consent as contemplated herein, the Landlord shall commence the Landlord’s Work in accordance with the terms of this Lease. Upon completion of the Landlord’s Work, the Landlord shall provide the Tenant receipted invoices verifying the actual cost of completing the Landlord’s Work in the Premises. It is acknowledged and agreed that in consideration for the Tenant being responsible for all the costs associated with the Landlord’s Work as contemplated herein, the cost of the Landlord’s Work shall be included in total amount subject recoverable by the Tenant and to the Free Rent Period (as hereinafter defined) subject to the terms and conditions of this Schedule “D” and the Lease, generally.
Landlord Work Prior to the execution of this First Amendment, Landlord and Tenant have approved (i) a detailed space plan for the construction of Landlord’s Work in the Premises, which space plan has been prepared by Studio O + A (“Final Approved Plan”) and (ii) a bid proposal for the construction of Landlord’s Work in the Premises, which bid proposal has been prepared by XX Xxxx Construction and is dated June 2, 2011 (Rev-2) (“Bid Proposal”). The Final Approved Plan and Bid Proposal are approved by the parties as of the Effective Date, are attached hereto collectively, as Exhibit “D-1” and hereby replaces the original Approved Plan attached to the Lease as Exhibit “D-1”. Consequently, all references in the Work Letter to the “Approved Plan” shall mean and refer to the Final Approved Plan and Bid Proposal attached hereto as Exhibit “D-1”. Landlord agrees to construct the Landlord Work, pursuant to the terms and conditions set forth in the Work Letter and as depicted on the Approved Plan (as amended hereby). Landlord shall pay for the cost (including, the cost of obtaining all applicable building permits) of the design and construction of Landlord’s Work in an amount up to, but not exceeding, Two Hundred Twenty Two Thousand One Hundred Fifty and 00/100 Dollars ($222,150.00) plus any additional costs actually incurred by Landlord in excess of such $222,150.00 amount as a direct result of Landlord’s or Landlord’s contractor’s active negligence or willful misconduct or resulting from change order to the Approved Plans (as amended hereby) if such change order is initiated and executed by Landlord (the “Landlord’s Contribution”). Tenant shall pay for all costs in excess of the Landlord’s Contribution (“Over Allowance Amount”) which payment shall be made to Landlord in cash within thirty (30) days after Tenant’s receipt of invoice therefor from Landlord. Payment of the Over-Allowance Amount shall be in addition to Tenant’s obligation to pay to Landlord the cost of any Aggregate Extras as provided in Section 4 of the Work Letter.
Tenant’s Work Landlord and Tenant acknowledge and agree that certain work required for Tenant's occupancy of the Leased Premises, including but not limited to the procurement and installation of furniture, fixtures, equipment, artwork and interior signage are beyond the scope of the Tenant Improvements and shall be performed by Tenant or its contractors at Tenant's sole cost and expense. All such work ("Tenant's Work") shall be subject to Landlord's prior written approval. Tenant shall adopt a construction schedule for Tenant's Work in conformance with the Contractor's schedule, and shall perform Tenant's Work in such a way as not to hinder or delay the operations of Landlord or the Contractor in the Building. Any costs incurred by Landlord as a result of any interference with Landlord's operations by Tenant or its contractors shall be promptly paid by Tenant to Landlord upon demand. Landlord shall make all reasonable efforts to notify Tenant of any such interference of which Landlord has actual knowledge, but failure to provide such notice shall in no way limit Landlord's right to demand payment for such costs. Tenant's contractors shall be subject to Landlord's prior written approval, and to the administrative supervision of the Contractor. Tenant's Work shall comply with all of the following requirements:
(a) Tenant's Work shall not proceed until Landlord has approved in writing: (i) Tenant's contractors, (ii) proof of the amount and coverage of public liability and property damage insurance carried by Tenant's contractors in the form of an endorsed insurance certificate naming Landlord, the Contractor, and the agents of Landlord and the Contractor as additional insureds, in an amount not less than two million dollars, and (iii) complete and detailed plans and specifications for Tenant's Work.
(b) Tenant's Work shall be performed in conformity with a valid permit when required, a copy of which shall be furnished to Landlord before such work is commenced. In any event, all Tenant's Work shall comply with all applicable laws, codes and ordinances of any governmental entity having jurisdiction over the Building. Landlord shall have no responsibility for Tenant's failure to comply with such applicable laws. Any and all delay in obtaining a certificate of occupancy due to Tenant's vendors is the responsibility of Tenant and shall be a Tenant Delay.
(c) In connection with Tenant's Work (e.g., delivering or installing furniture or equipment to the second floor of the Leased Premises), Tenant or its contractors shall arrange for any necessary hoisting or elevator service with Landlord and shall pay such reasonable costs for such services as may be charged by Landlord.
(d) Tenant shall promptly pay Landlord upon demand for any extra expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, by reason of damage to existing work caused by Tenant or its contractors, or by reason of inadequate cleanup by Tenant or its contractors.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter:
a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications).
b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows:
(i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and
(ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, Xxxxxxxxx XxxXxxx of Xxxxx Xxxx LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises.
c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Tenant Improvement Allowance Commencing as of January 1, 2011, Tenant shall be entitled to use the “Tenant Improvement Allowance”, as defined in Section 2 of this Amendment, for the costs relating to the design and construction of Tenant’s improvements or which are otherwise “Tenant Improvement Allowance items,” as that term is defined in Section 2.2.1, below (collectively, the “Tenant Improvements”). In no event shall Landlord be obligated to make disbursements pursuant to this Tenant Work Letter or otherwise in connection with Tenant’s construction of the Tenant Improvements or any Tenant Improvement Allowance Items, as defined below, in a total amount which exceeds the sum of the Tenant Improvement Allowance. All Tenant Improvements for which the Tenant Improvement Allowance has been made available shall be deemed Landlord’s property under the terms of the Lease; provided, however, Landlord may, by written notice to Tenant given concurrently with Landlord’s approval of the “Final Working Drawings”, as that term is defined in Section 3.3, below, require Tenant, prior to the end of the Lease Term or promptly following any earlier termination of this Lease, at Tenant’s expense, to remove any Tenant Improvements and to repair any damage to the Premises and Building caused by such removal and return the affected portion of the Premises to a Building standard general office condition; provided, however, that Landlord shall not require Tenant to remove upon termination or expiration of this Lease, or condition its approval upon Tenant’s agreement to remove upon termination or expiration of this Lease, any Tenant Improvements constructed pursuant to this Tenant Work Letter (including, without limitation, Larc improvements) which constitute standard, non-extraordinary improvements for ordinary office, laboratory and/or Larc uses in biotech facilities. Any portion of the Tenant Improvement Allowance that is not disbursed or allocated for disbursement by December 31, 2013, shall revert to Landlord and Tenant shall have no further rights with respect thereto.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.