Covering and Uncovering Work Sample Clauses

Covering and Uncovering Work. 3.4.3.1 Re-examination or Re-testing of Work Covered Pursuant to Consent of Design Professional. Re- examination or re-testing of questioned Work previously covered pursuant to consent of the Design Professional may be ordered by the Design Professional. If so ordered the Work must be uncovered by the Contractor. The Owner shall pay the cost of re-examination and replacement or of re-testing if such Work is found in accordance with the Contract Documents. The Contractor shall pay such cost if such Work is found not in accordance with the Contract Documents unless the Contractor can show that a Separate Contractor caused the defect in the Work. In that event, the Owner shall pay such cost. Re-examination or re-testing under the terms of this Paragraph applies only to Work that has been covered with consent of the Design Professional. Work covered without consent of the Design Professional must be uncovered for examination as provided below.
Sample 1Sample 2Sample 3See All (92)
AutoNDA by SimpleDocs
Covering and Uncovering Work. 3.6.6 Inspection Does Not Relieve Design-Builder.
Sample 1Sample 2Sample 3See All (16)
Covering and Uncovering Work. 3.6.5.1 Re-examination or Re-testing of Work Covered Pursuant to Consent of Design Professional. Re-examination or re-testing of questioned Work previously covered pursuant to consent of the Design Professional may be ordered by the Design Professional. If so ordered the Work must be uncovered by the CM/GC. The Owner shall pay the cost of re-examination and replacement or of re-testing if such Work is found in accordance with the Contract Documents. The CM/GC shall pay such cost if such Work is found not in accordance with the Contract Documents unless the CM/GC can show that a Separate CM/GC caused the defect in the Work. In that event, the Owner shall pay such cost. Re-examination or re-testing under the terms of this Paragraph applies only to Work that has been covered with consent of the Design Professional. Work covered without consent of the Design Professional must be uncovered for examination as provided below.
Sample 1Sample 2Sample 3See All (7)
Covering and Uncovering Work. 3.6.6 Inspection Does Not Relieve CM/GC.
Sample 1Sample 2Sample 3See All (6)
Covering and Uncovering Work. Design-Build Entity must provide notice to Owner as to the schedule for covering Work so that the Owner has adequate time to observe Work to be covered. Owner may require any Work to be uncovered, whether or not prior information was provided as to the schedule for covering. Should Work so uncovered prove to be in non-compliance with the Contract Documents, the cost of uncovering, correction of the Work and re-covering shall be borne by the Design-Build Entity and the Owner is not be liable for any schedule recovery costs Design-Build Entity may incur. If Design-Build Entity provided adequate notice of covering and the work is compliant with the Contract Documents, Design-Build Entity is entitled to a change order for any extra cost caused Design-Build Entity, including any cost of schedule recovery. Design-Build Entity may comply with the notice requirements of this section as part of the project schedules described in Section 8.2 of the Design-Build Agreement.
Sample 1

Related to Covering and Uncovering Work

  • Uncovering and Correction of Work 12 Uncovering of Work 12.1 Unforeseen Conditions, Concealed or Unknown 3.7.4, 8.3.1, 10.3 Unit Prices 7.3.3.2, 9.1.2

  • UNCOVERING OF WORK 13.1.1 If any portion of the Work should be covered contrary to the request of the Architect or to requirements specifically expressed in the Contract Documents, it must, if required in writing by the Architect, be uncovered for his or her observation and shall be replaced at the Contractor's expense.

  • Additional Wet Weather Procedure 14.15.1 Remaining On Site Where, because of wet weather, the employees are prevented from working:

  • BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply:

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:

  • Participating TO's Interconnection Facilities Construction The Participating TO's Interconnection Facilities shall be designed and constructed in accordance with Good Utility Practice. Upon request, within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Participating TO and Interconnection Customer agree on another mutually acceptable deadline, the Participating TO shall deliver to the Interconnection Customer and the CAISO the following “as-built” drawings, information and documents for the Participating TO's Interconnection Facilities [include appropriate drawings and relay diagrams]. The Participating TO will obtain control for operating and maintenance purposes of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades upon completion of such facilities. Pursuant to Article 5.2, the CAISO will obtain Operational Control of the Stand Alone Network Upgrades prior to the Commercial Operation Date.

  • OCCUPANCY AND USE Except for (i) the period of time permitted by this Lease for Tenant to perform Tenant's Work to prepare the Premises for Tenant's initial occupancy as set forth in Section 3.2.1 and (ii) a period of six (6) months at the end of the Term, and (iii) temporary vacancies of not more than forty percent (40%) of the Premises at any one time, continuously from the Commencement Date, to use and occupy the Premises only for the Permitted Uses, and from time to time, to procure all licenses and permits necessary therefor at Tenant's sole expense, and to the extent set forth in Section 10.21 hereof, with Landlord's cooperation. Without limitation, Tenant shall comply in all material respects with all federal, state, and municipal laws, ordinances, and regulations governing, and all Development Approvals, Subsequent Approvals and Title Exceptions applicable to, Tenant's particular use or manner of use of the Premises. Tenant shall be solely responsible for procuring and complying at all times with any and all necessary permits directly relating or incident to: the conduct of its office activities on the Premises; its, transportation, storage, handling, use and disposal of any chemical or radioactive or bacteriological or pathological substances or organisms or other hazardous wastes or environmentally dangerous substances or materials or medical waste. Within thirty (30) days of a request by Landlord, which request shall be made not more than once during each period of twelve (12) consecutive months during the Term hereof, unless otherwise requested by any mortgagee of Landlord, Tenant shall furnish Landlord with copies of all such permits which Tenant possesses or has obtained together with a certificate certifying that such permits are all of the permits which Tenant possesses or has obtained with respect to the Premises. Tenant shall be entitled to redact any Confidential Information from the copies of such permits and accompanying certificates of Tenant. Tenant shall promptly give notice to Landlord of any warnings or violations relative to the matters described in this Section 5.1.2 received from any federal, state, or municipal agency or by any court of law and shall promptly cure the conditions causing any such violations. Tenant shall not be deemed to be in default of its obligations under the preceding sentence to promptly cure any condition causing any such violation in the event that, in lieu of such cure, Tenant shall contest the validity of such violation by appellate or other proceedings permitted under applicable law, provided that: (i) any such contest is made reasonably and in good faith, (ii) Tenant makes provisions, including, without limitation, posting bond(s) or giving other security, acceptable to Landlord to protect Landlord, the Building, the Lot and the Complex from any liability, costs, damages or expenses arising in connection with such violation and failure to cure, (iii) Tenant shall agree to indemnify, defend (with counsel reasonably acceptable to Landlord) and hold Landlord harmless from and against any and all liability, costs, damages, or expenses arising in connection with such condition and/or violation, (iv) Tenant shall promptly cure any violation in the event that its appeal of such violation is overruled or rejected, and (v) Tenant shall certify to Landlord's satisfaction that Tenant's decision to delay such cure shall not result in any actual or threatened bodily injury or property damage to Landlord, any tenant or occupant of the Building, the Lot or the Complex, or any other person or entity. Landlord agrees that any Confidential Information gained or obtained by Landlord pursuant to this Section 5.1.2 shall be kept confidential in accordance with Section 10.15 hereof.

  • TERM AND SCOPE OF THE CIA A. This CIA shall have a term of five years from the Effective Date. The Effective Date shall be the date on which the final signatory signs this CIA. Each one- year period, beginning with the one-year period following the Effective Date, shall be referred to as a “Reporting Period.”

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!