Service Interruptions When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, or by reason of event(s) of Force Majeure, Landlord reserves the right to interrupt, curtail, stop or suspend (i) the furnishing of heating, elevator, air conditioning, and cleaning services and (ii) the operation of the plumbing and electric systems. Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but there shall be no diminution or abatement of rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of the Tenant’s obligations hereunder reduced, and the Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems, except as provided herein. Landlord shall schedule all non-emergency interruptions, curtailments, stops or suspensions of services or systems in advance after consultation with Tenant, and shall make commercially reasonable efforts to avoid the same interfering with Tenant’s business. Notwithstanding the foregoing, Tenant shall be entitled to a proportionate abatement of Base Rent in the event of a Landlord Service Interruption (as defined below). For the purposes hereof, a “Landlord Service Interruption” shall occur in the event (i) the Premises shall lack any service which Landlord is required to provide hereunder thereby rendering at least fifty (50%) percent of the usable area of the Premises untenantable for the entirety of the Landlord Service Interruption Cure Period (as defined below), (ii) such lack of service was not caused by the act or omission of Tenant or any Tenant Party; (iii) Tenant in fact ceases to use at least fifty (50%) percent of the Premises for the entirety of the Landlord Service Interruption Cure Period; and (iii) such interruption of service was the result of causes, events or circumstances within the Landlord’s reasonable control and the cure of such interruption is within Landlord’s reasonable control. During such Landlord Service Interruption Period, Landlord will, if reasonably practical, cooperate with Tenant to arrange for the provision of any interrupted services on an interim basis via temporary measures until final corrective measures can be accomplished and Tenant will permit Landlord the necessary access to the Premises to remedy such lack of service, subject to the provisions of Section 9.06. For the purposes hereof, the “Landlord Service Interruption Cure Period” shall be defined as seven (7) consecutive Business Days after Landlord’s receipt of written notice from Tenant of the Landlord Service Interruption. This Section 6.03 shall be Tenant’s sole and exclusive remedy on account of an interruption of services or Landlord default resulting in an interruption of services other than Tenant’s right to obtain affirmative injunctive relief. This Section 6.03 shall not apply to any interruption or failure of services required to be provided by Landlord under Section 6.02(a) or Exhibit E attached hereto, which is caused in whole or in part by any act or omission of Tenant or any Tenant Party, or by any occurrence described in Section 16.09, or by any cause whatsoever other than those set forth in the first sentence of this Section 6.03. Notwithstanding the foregoing, if either Landlord or Tenant disputes in good faith whether, or the extent to which, an event is subject to the provisions of this Section 6.03, or the amount of Tenant’s abatement of Base Rent hereunder, such dispute shall be resolved in accordance with Section 16.17 of this Lease; provided, however, that in the event that it is ultimately determined that there was a Landlord Service Interruption, then Tenant shall have the right to a retroactive equitable abatement of Base Rent for the period as set forth above, provided that, if the Term expires before Tenant’s entire retroactive abatement has been effected, then Landlord shall immediately refund to Tenant any overpayment of Rent due under the Lease not yet received on account of the retroactive abatement.
Interruptions There shall be no abatement of rent and Lessor shall not be liable in any respect whatsoever for the inadequacy, stoppage, interruption or discontinuance of any utility or service due to riot, strike, labor dispute, breakdown, accident, repair or other cause beyond Lessor's reasonable control or in cooperation with governmental request or directions.
Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Interruption of Services Tenant agrees that Landlord shall not be liable in damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service, or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by repairs, renewals, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building after reasonable effort so to do, by any accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord’s reasonable control; and such failures or delays or diminution (any such event, a “Service Failure”) shall never be deemed to constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Notwithstanding the foregoing, if the Premises, or a material portion of the Premises, is made untenantable (that is, Tenant cannot conduct its business in such portion) or inaccessible for a period in excess of five (5) consecutive business days as a result of the Service Failure that has been caused by Landlord’s act or omission with respect to matters within Landlord’s control (“Controlled Service Failure”), then Tenant, as its sole remedy, shall be entitled to receive an abatement of Rent payable hereunder during the period beginning on the sixth (61 ) consecutive business day of the Controlled Service Failure and ending on the day the service has been restored. If the entire Premises has not been rendered untenantable or inaccessible by such a Controlled Service Failure, the amount of abatement that Tenant is entitled to receive by reason of such a Controlled Service Failure shall be prorated based upon the percentage of the Premises rendered untenantable or inaccessible and not used by Tenant. Notwithstanding the foregoing, business days during which the Premises or a material portion thereof are untenantable or inaccessible, or during which all or nearly all the Premises are unusable, by reason of a Service Failure which arises from a fire or other casualty which is covered by the provisions of ARTICLE 13 shall in no event be considered in determining whether Tenant is entitled to an abatement of Rent under this Section 8.03 (in such event the provisions of Section 13.01 shall govern Tenant’s rights). In no event shall Landlord be liable to Tenant for any loss or damage, including the theft of Tenant’s property, arising out of or in connection with the failure of any security services, personnel or equipment.
Interruption of Use Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord's reasonable control; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant's use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for a loss of, or injury to, property or for injury to, or interference with, Tenant's business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6.
Interruption of Service The service of the Director shall not be deemed to have been terminated or interrupted due to his absence from active service on account of illness, disability, during any authorized vacation or during temporary leaves of absence granted by the Bank for reasons of professional advancement, education, health or government service, or during military leave for any period if the Director is elected to serve on the Board following such interruption.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Excusable Delays Neither Party shall be held liable for any delay or failure in performance of any part of this Services Agreement by reason of any cause beyond its reasonable control, including, but not limited to, acts of God, acts of civil or military authority, government regulations, embargoes, epidemics, war, terrorist acts, riots, fires, explosions, earthquakes, nuclear accidents, floods, strikes, power blackouts affecting facilities, inability to secure products or services of other persons or transportation facilities, or acts or omissions of transportation common carriers, provided that the Party so affected shall use reasonable commercial efforts to remove such causes of non-performance. Upon the occurrence of any event of force majeure, the Party whose performance is prevented shall promptly give written notice to the other Party and the Parties shall promptly confer in good faith to agree upon reasonable action to minimize the impact of such event on the Parties.
Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.
