Decommissioning and Abandonment Guarantees Sample Clauses

Decommissioning and Abandonment Guarantees. The Contractor shall provide decommissioning and abandonment guarantee as of the Production Start Date, and, for that, it may use: performance bond; letter of credit; support fund; or other types of guarantees, at ANP’s discretion. The amount of the decommissioning and abandonment guarantee for a Development Area or Field shall be reviewed at the request of the Contractor or ANP, whenever there are events that change the cost of abandonment and decommissioning of Operations. The guarantee provided by the Contractor shall be equivalent to the expected cost for decommissioning and abandonment of the infrastructure already implemented. In the case of a guarantee provided through a support fund: the Contractors shall submit to ANP, every 15th of February and August each year, supporting documentation for the contributions made, as well as inform the adjusted balance of the fund; ANP may audit the procedures adopted by the Contractors in management of the support fund; the balance ascertained after all Operations required for decommissioning and abandonment of the Field are conducted shall be for the sole benefit of the Contracting Party. The provision of a decommissioning and abandonment guarantee does not exempt the Consortium Members from the obligation to execute all Operations required for decommissioning and abandonment of the Field. Pursuant to articles 29, XV, and 32, paragraphs 1 and 2, of Law No. 12,351/2010, any and all personal and real properties, principal and ancillary, forming part of the Concession Area and that, at the Contracting Party’s sole discretion, based on ANP’s opinion, are necessary to enable continuity of the Operations or which use is considered of public interest shall become owned by the Federal Government and be managed by ANP in case of termination of this Agreement or relinquishment of plots of the Contract Area. Properties used in the Operations that are subject matter of a rental, lease, or charter agreement which useful life does not extend beyond the effectiveness of the Agreement and shall not become owned by the Contracting Party or by ANP’s management. With respect to properties which useful life extends beyond the effectiveness of the Agreement, the Contractor shall include in the rental, lease, or charter agreement a section that allows its assignment or renewal with a future Contractor, aiming at ensuring continuity of the Operations, as provided for in paragraph 14.9. In case properties are shared for Operations in ...
Sample 1Sample 2Sample 3See All (22)
AutoNDA by SimpleDocs
Decommissioning and Abandonment Guarantees. The Contractor shall provide a decommissioning and abandonment guarantee as of the Production Start Date, and, for that, it may use:
Sample 1Sample 2Sample 3See All (21)
Decommissioning and Abandonment Guarantees. The Contracted Party shall provide decommissioning and abandonment guarantee as of the Production Start Date, and, therefor, it may use:
Sample 1Sample 2Sample 3See All (6)

Related to Decommissioning and Abandonment Guarantees

  • Cooperation on forestry matters and environmental protection 1. The aims of cooperation on forestry matters and environmental protection will be, but not limited to, as follows: (a) establishing bilateral cooperation relations in the forestry sector; (b) developing a training program and studies for sustainable management of forests; (c) improving the rehabilitation and sustainable management of forest with the aim of increasing carbon sinks and reduce the impact of climate change in the Asia-Pacific region; (d) cooperating on the execution of national projects, aimed at: improving the management of forest plantations for its transformation for industrial purposes and environmental protection; (e) elaborating studies on sustainable use of timber; (f) developing new technologies for the transformation and processing of timber and non-timber species; and (g) improving cooperation in agro-forestry technologies. 2. To achieve the objectives of the Article 149 (Objectives), the Parties may focus, as a means of cooperation and negotiations on concluding a bilateral agreement on forestry cooperation between the two Parties. Such collaboration will be as follows: (a) exchanges on science and technology as well as policies and laws relating the sustainable use of forest resources; (b) cooperation in training programs, internships, exchange of experts and projects advisory; (c) advice and technical assistance to public institutions and organizations of the Parties on sustainable use of forest resources and environmental protection; (d) facilitating forest policy dialogue and technical cooperation under the Network of Sustainable Forest Management and Forest Rehabilitation in Asia- Pacific Region, initiated at the 15th Asia Pacific Economic Cooperation (APEC) Meeting; (e) encouraging joint studies, working visits, exchange of experiences, among others; and (f) others activities mutually agreed.

  • Environmental, Health and Safety Matters (a) Comply in all material respects with all applicable Environmental Laws, including, without limitation, obtaining and complying with and maintaining any and all licenses, approvals, notifications, registrations or permits required by applicable Environmental Laws. For purposes of this Section 5.12(a), material noncompliance by the Company, any of its Subsidiaries or any tenant or subtenant, with any applicable Environmental Law shall be deemed not to constitute a breach of this covenant provided that, upon learning of any actual or suspected material noncompliance, the Company and the relevant Subsidiaries shall promptly undertake all reasonable efforts to achieve material compliance (or contest in good faith by appropriate proceedings the alleged violation or applicable Environmental Law at issue and (to the extent required by GAAP) provide on the books of the Company or any of its Subsidiaries, as the case may be, reserves in accordance with GAAP with respect thereto), and provided further that, in any case, such noncompliance, and any other noncompliance with applicable Environmental Law, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect. (b) Promptly comply in all material respects with all lawful orders and directives of all Governmental Authorities regarding applicable Environmental Laws, except to the extent that the validity thereof is currently being contested in good faith by appropriate proceedings and (to the extent required by GAAP) reserves in accordance with GAAP with respect thereto have been provided on the books of the Company or any of its Subsidiaries, as the case may be. (c) Defend, indemnify and hold harmless the Administrative Agent and the Lenders, and their respective parents, subsidiaries, affiliates, employees, agents, officers and directors, from and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs and expenses of whatever kind or nature, known or unknown, contingent or otherwise, arising out of, or in any way relating to the violation of, noncompliance with or liability under any Environmental Laws applicable to the Company or any of its Subsidiaries or any of their respective operations or properties, or any orders, requirements or demands of Governmental Authorities related thereto, including, without limitation, attorney’s and consultant’s fees, investigation and laboratory fees, response costs, court costs and litigation expenses, except to the extent that any of the foregoing arise out of the gross negligence or willful misconduct of (or, as determined pursuant to a claim initiated by the Company, breach in bad faith of its express obligations under the applicable Loan Documents by) the party seeking indemnification therefor, in each case, as determined by a final non-appealable judgment by a court of competent jurisdiction. This indemnity shall continue in full force and effect regardless of the termination of this Agreement.

  • Environmental and Safety Matters (a) The Company and its Subsidiaries have at all times complied in all material respects with all applicable Environmental and Safety Requirements, which compliance has included obtaining and complying in all material respects at all times with all material permits, licenses and other authorizations required pursuant to Environmental and Safety Requirements for the occupation of their facilities and the operation of their respective businesses. (b) Except as set forth in Section 4.27(b) of the Disclosure Schedule, since February 19, 2008, neither the Company nor any of its Subsidiaries has received any notice, report, order, or directive regarding any, and is not subject to any litigation, proceedings or order regarding any, actual or alleged violation of Environmental and Safety Requirements, or any liability or potential liability arising under Environmental and Safety Requirements, in effect prior to and as of the date of the applicable Closing, relating to the business, the Owned Real Property or Leased Real Property. (c) Except as set forth in Section 4.27(c) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has treated, stored, disposed of, arranged for or permitted the disposal of, transported, handled, released, or exposed any Person to, any substance (including without limitation any hazardous substance), owned or operated any property or facility which is or has been contaminated by any substance, so as to give rise to any current or future liabilities under any Environmental and Safety Requirements in effect at the time of such treatment, storage, disposal, transportation, handling, release or exposure. (d) Except as set forth in Section 4.27(d) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has assumed, undertaken, or provided any indemnity with respect to, any liability of any other Person relating to Environmental and Safety Requirements. (e) The Company has furnished to Investor true and correct copies of all environmental audits, reports, assessments and all other documents materially bearing on environmental, health or safety liabilities relating to the past or current operations or facilities of the Company and all of its Subsidiaries, in each case which are in its possession or under its reasonable control.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Access to Properties and Records (a) CCE shall, and shall cause TPC to, afford to ETP and ETP’s accountants, counsel and representatives full reasonable access during normal business hours throughout the period prior to the Closing Date (or the earlier termination of this Agreement pursuant to Article VII hereof) to all of the properties, books, contracts, commitments and records (including all environmental studies, reports and other environmental records and all pipeline cost-of-service and rate-related studies, reports and records related to TPC and, during such period, shall furnish to ETP all information concerning the business, properties, Liabilities and personnel related to TPC as ETP may request, provided, however, that no investigation or receipt of information pursuant to this Section 5.2 shall affect any representation or warranty of CCE or the conditions to the obligations of ETP. To the extent not located at the offices or properties of TPC as of the Closing Date, as promptly as practicable thereafter, CCE shall deliver, or cause its appropriate Affiliates to deliver to ETP all of the books of accounts, minute books, record books and other records (including safety, health, environmental, maintenance and engineering records and drawings) pertaining to the business operations of TPC and all financial and accounting records related to TPC. Such delivery shall include all work papers, pleadings, testimony, exhibits, spread sheets, research, drafts, memoranda, correspondence and other documents related to the TPC Rate Case (“TPC Rate Case Work Product”). TPC Rate Case Work Product has been and will be prepared in contemplation of litigation, and the use of TPC Rate Case Work Product has been and will be under the control of TPC’s attorneys. Notwithstanding anything to the contrary contained in this Agreement, CCE shall not be obligated to provide to ETP any documents or records relating to litigation and regulatory matters in which TPC is involved to the extent that CCE reasonably believes such documents or records are subject to the attorney-client or other applicable privilege in circumstances in which TPC is not the sole client unless the parties entitled to such attorney-client or other applicable privilege shall consent thereto and enter into an appropriate joint defense agreement for the purpose of preservation of such attorney-client or other applicable privilege. (b) The information contained herein, in the CCE Disclosure Letter or heretofore or hereafter delivered to ETP or its authorized representatives in connection with the transactions contemplated by this Agreement shall be held in confidence by ETP and its representatives in accordance with the Confidentiality Agreement until the Closing Date with respect to information relating to TPC. Following the Closing Date, CCE shall keep confidential all information related to the business and properties of TPC to the same extent as ETP is obligated to keep such information confidential in accordance with the terms of the Confidentiality Agreement (without regard to the preceding sentence) prior to the Closing Date.

  • Access to Properties Subject to the rights of Tenants, Borrower shall permit agents, representatives and employees of Lender to inspect the Properties or any part thereof at reasonable hours upon reasonable advance notice.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • OBLIGATIONS AND ACTIVITIES OF CONTRACTOR AS BUSINESS ASSOCIATE 1. CONTRACTOR agrees not to use or further disclose PHI COUNTY discloses to CONTRACTOR other than as permitted or required by this Business Associate Contract or as required by law. 2. XXXXXXXXXX agrees to use appropriate safeguards, as provided for in this Business Associate Contract and the Agreement, to prevent use or disclosure of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY other than as provided for by this Business Associate Contract. 3. XXXXXXXXXX agrees to comply with the HIPAA Security Rule at Subpart C of 45 CFR Part 164 with respect to electronic PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY. 4. CONTRACTOR agrees to mitigate, to the extent practicable, any harmful effect that is known to CONTRACTOR of a Use or Disclosure of PHI by CONTRACTOR in violation of the requirements of this Business Associate Contract. 5. XXXXXXXXXX agrees to report to COUNTY immediately any Use or Disclosure of PHI not provided for by this Business Associate Contract of which CONTRACTOR becomes aware. CONTRACTOR must report Breaches of Unsecured PHI in accordance with Paragraph E below and as required by 45 CFR § 164.410. 6. CONTRACTOR agrees to ensure that any Subcontractors that create, receive, maintain, or transmit PHI on behalf of CONTRACTOR agree to the same restrictions and conditions that apply through this Business Associate Contract to CONTRACTOR with respect to such information. 7. CONTRACTOR agrees to provide access, within fifteen (15) calendar days of receipt of a written request by COUNTY, to PHI in a Designated Record Set, to COUNTY or, as directed by COUNTY, to an Individual in order to meet the requirements under 45 CFR § 164.524. If CONTRACTOR maintains an Electronic Health Record with PHI, and an individual requests a copy of such information in an electronic format, CONTRACTOR shall provide such information in an electronic format. 8. CONTRACTOR agrees to make any amendment(s) to PHI in a Designated Record Set that COUNTY directs or agrees to pursuant to 45 CFR § 164.526 at the request of COUNTY or an Individual, within thirty (30) calendar days of receipt of said request by COUNTY. XXXXXXXXXX agrees to notify COUNTY in writing no later than ten (10) calendar days after said amendment is completed. 9. CONTRACTOR agrees to make internal practices, books, and records, including policies and procedures, relating to the use and disclosure of PHI received from, or created or received by CONTRACTOR on behalf of, COUNTY available to COUNTY and the Secretary in a time and manner as determined by COUNTY or as designated by the Secretary for purposes of the Secretary determining COUNTY’S compliance with the HIPAA Privacy Rule. 10. CONTRACTOR agrees to document any Disclosures of PHI COUNTY discloses to CONTRACTOR or CONTRACTOR creates, receives, maintains, or transmits on behalf of COUNTY, and to make information related to such Disclosures available as would be required for COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528. 11. CONTRACTOR agrees to provide COUNTY or an Individual, as directed by COUNTY, in a time and manner to be determined by COUNTY, that information collected in accordance with the Agreement, in order to permit COUNTY to respond to a request by an Individual for an accounting of Disclosures of PHI in accordance with 45 CFR § 164.528. 12. XXXXXXXXXX agrees that to the extent CONTRACTOR carries out COUNTY’s obligation under the HIPAA Privacy and/or Security rules CONTRACTOR will comply with the requirements of 45 CFR Part 164 that apply to COUNTY in the performance of such obligation. 13. If CONTRACTOR receives Social Security data from COUNTY provided to COUNTY by a state agency, upon request by COUNTY, CONTRACTOR shall provide COUNTY with a list of all employees, subcontractors and agents who have access to the Social Security data, including employees, agents, subcontractors and agents of its subcontractors. 14. CONTRACTOR will notify COUNTY if CONTRACTOR is named as a defendant in a criminal proceeding for a violation of HIPAA. COUNTY may terminate the Agreement, if CONTRACTOR is found guilty of a criminal violation in connection with HIPAA. COUNTY may terminate the Agreement, if a finding or stipulation that CONTRACTOR has violated any standard or requirement of the privacy or security provisions of HIPAA, or other security or privacy laws are made in any administrative or civil proceeding in which CONTRACTOR is a party or has been joined. COUNTY will consider the nature and seriousness of the violation in deciding whether or not to terminate the Agreement.

  • Contracts Concerning Use of Project The Recipient agrees that during the Agreement Term it will not contract with any Private Person for use of the Project or any portion thereof or the facility or facilities of which the Project is a part for any Private Business Use unless all of the conditions of subparagraph F.3.a., subparagraph F.3.b. or subparagraph F.3.c. are met: a. If the compensation of the Private Person is based entirely on a periodic, fixed fee that contains no incentive adjustments, all of the following conditions must be met: (A) no amount of compensation is based on a share of the net profits; (B) the compensation is reasonable; (C) the term of the contract does not exceed five (5) years (including any renewal option periods provided for in the contract);

  • Environmental Compliance and Reports Borrower shall comply in all respects with any and all Environmental Laws; not cause or permit to exist, as a result of an intentional or unintentional action or omission on Borrower’s part or on the part of any third party, on property owned and/or occupied by Borrower, any environmental activity where damage may result to the environment, unless such environmental activity is pursuant to and in compliance with the conditions of a permit issued by the appropriate federal, state or local governmental authorities; shall furnish to Lender promptly and in any event within thirty (30) days after receipt thereof a copy of any notice, summons, lien, citation, directive, letter or other communication from any governmental agency or instrumentality concerning any intentional or unintentional action or omission on Borrower’s part in connection with any environmental activity whether or not there is damage to the environment and/or other natural resources. Additional Assurances. Make, execute and deliver to Lender such promissory notes, mortgages, deeds of trust, security agreements, assignments, financing statements, instruments, documents and other agreements as Lender or its attorneys may reasonably request to evidence and secure the Loans and to perfect all Security Interests.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!