Defects Liability Period (i) The Contractor shall be responsible for all the Defects and deficiencies, except usual wear and tear in the Project Highway or any Section thereof, till the expiry of a period of commencing from the date of Completion Certificate (the “Defects Liability Period”) as specified below:
(a) 5 (five) years from the date of completion in case of a road being constructed with flexible pavement;
(b) 10 (ten) years from the date of completion in case of road being constructed with rigid pavement;
(c) 10 (ten) years from the date of completion in case of road being constructed with flexible pavement using perpetual design;
(d) 10 (ten) years from the date of completion in case of all stand-alone structures, e.
Products Liability (a) Except as set forth on Schedule 3.25, (i) there is no Action before any Governmental Entity pending, or to the Knowledge of the Seller, threatened against the Company involving any products manufactured, produced, distributed or sold by or on behalf of the Company and/or in connection with the Business (including any parts or components) (collectively, “Products”), or class of claims or lawsuits involving the same or similar Product which is pending or, to the Seller’s Knowledge, threatened, resulting from an alleged defect in design, manufacture, materials or workmanship of any Product, or any alleged failure to warn, or from any breach of implied warranties or representations (collectively, “Product Liability Lawsuits”); (ii) there has not been, within the past 12 months, any Occurrence (as hereinafter defined); and (iii) there has not been, within the past 12 months, any Product rework or retrofit (collectively, “Retrofits”) conducted by or on behalf of the Company.
(b) For purposes of this Section 3.25, the term “Occurrence” shall mean any accident, happening or event which takes place at any time which is caused or allegedly caused by any alleged hazard or alleged defect in manufacture, design, materials or workmanship including, without limitation, any alleged failure to warn or any breach of express or implied warranties or representations with respect to, or any such accident, happening or event otherwise involving any Product that can reasonably be expected to result in a claim or loss.
(c) Except as set forth on Schedule 3.25, to the Seller’s Knowledge, each Product manufactured, sold, leased, or delivered by the Company and the Business has been in conformity with all applicable material contractual commitments and all express and implied warranties, and the Company and the Business have no Liability (and there is no basis for any present or future proceeding against any of them giving rise to any Liability) for replacement or repair thereof or other damages in connection therewith. No Product manufactured, sold, leased, or delivered by the Company and the Business is subject to any guaranty, warranty, or other indemnity beyond the applicable standard terms and conditions of sale or lease. Schedule 3.25 includes copies of the standard terms and conditions of sale or lease for the Company and the Business (containing applicable guaranty, warranty, and indemnity provisions). Except as set forth on Schedule 3.25, the Seller and the Business have no obligation to any person to maintain, modify, improve or upgrade any of the Products.
(d) Except as set forth on Schedule 3.25, to the Seller’s Knowledge, the Company and the Business have no material Liability (and there is no basis for any present or future proceeding against any the Company and the Business giving rise to any material Liability) arising out of any injury to individuals or property as a result of the ownership, possession, or use of any Product manufactured, sold, leased, or delivered by the Company and the Business.
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Defects Liability 9.1 In this Contract, and subject to Clause 9.2, a defect shall mean any non-conformity of the Supplies with the express terms of this Contract resulting from circumstances existing in the Supplies at the time of the transfer of risk to the Customer (“Defects”).
9.2 In particular, the following shall not be Defects:
a) normal wear and tear, non-conformity resulting from excessive strain,
b) non-conformity resulting from faulty or negligent handling; non-compliance with instructions or recommendations in operation or maintenance manuals and other documents;
c) installation, erection, modification, commissioning, or pre-commissioning, in each case not carried out by Xxxxxxx,
d) non-reproducible software errors,
e) defects which do not significantly impair the use of the respective Supplies.
9.3 The Customer shall immediately inspect the Supplies upon delivery and shall notify Flender in writing of any Defects without undue delay. The Customer’s claims in respect of defects shall be excluded for any apparent defects if the Customer has failed to do so. Upon such written notification, Flender shall, at its option, remedy a Defect by repair, replacement, or re-performance. Flender shall be given a reasonable period of time and opportunity to remedy the Defect. For this purpose, the Customer shall xxxxx Xxxxxxx working access to the non- conforming Supplies, shall undertake any necessary dis-assembly and re-assembly, and shall provide access to operation and maintenance data, all at no charge to Flender. Upon Flender’s request, the Customer shall ensure that the title to the replaced parts/items shall pass to Flender.
9.4 Unless otherwise agreed, the defects liability period for any part of the Supplies is 12 months. It starts at the date of transfer of risk. For replaced or repaired parts of the Supplies, the defects liability period is 6 months from the date of replacement or repair, if the original defects liability period for the Supplies expires earlier. In any event, the defects liability period shall end no later than 24 months from the beginning of the original defects liability period.
9.5 If software is defective, Flender shall only be obliged to provide the Customer with an updated version of the software in which the Defect has been remedied when such updated version is reasonably available from Flender or, if Flender is only licensee, from Flender’s licensor. If the software has been modified or individually developed by Flender, Flender shall in addition provide the Customer with a workaround or other interim corrective solution until the provision of an updated version of the software, if such workaround or interim solution is feasible at reasonable expense and if otherwise the Customer’s business operations would be substantially impeded.
9.6 If Flender carries out remedial work and it is ultimately not established that there was a Defect, the Customer shall pay Flender for such remedial work including error diagnosis.
9.7 Any other liability of Flender and rights and remedies of the Customer in case of defects of the Supplies, other than those expressly stipulated in this Clause 9 or , in case Flender failed at least three times in remedying the defect, in Clause 15.2b) shall be excluded. All warranties, representations, conditions, and all other terms of any kind whatsoever implied by statute or law are, to the fullest extent permitted by applicable law, excluded from this Contract.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Limitation of Guarantor's Liability Each Guarantor and by its acceptance of Notes, each Holder, confirms that it is the intention of all such parties that the Note Guarantee of such Guarantor not constitute a fraudulent transfer or conveyance for purposes of the Federal Bankruptcy Code, the Uniform Fraudulent Conveyance Act, the Uniform Fraudulent Transfer Act or any similar federal or state law relating to fraudulent transfer or conveyance. To effectuate the foregoing intention, the Trustee, the Holders and Guarantors hereby irrevocably agree that the obligations of such Guarantor under its Note Guarantee shall be limited to the maximum amount that will not, after giving effect to all other contingent and fixed liabilities of such Guarantor and after giving effect to any collections from, rights to receive contribution from or payments made by or on behalf of any other Guarantor in respect of the obligations of such other Guarantor under its Note Guarantee, result in the obligations of such Guarantor under its Note Guarantee constituting a fraudulent transfer or conveyance.
Limitation of Seller's Liability This paragraph limits the liability of the seller. This is a usual provision, but flexible, ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ . ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ , ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ .
Our Liability (a) The quality and reliability of your electricity supply and the quality, pressure and continuity of your gas supply is subject to a variety of factors that are beyond our control as your retailer, including accidents, emergencies, weather conditions, vandalism, system demand, the technical limitations of the distribution system and the acts of other persons (such as your distributor), including at the direction of a relevant authority.
(b) To the extent permitted by law, we give no condition, warranty or undertaking, and we make no representation to you, about the condition or suitability of energy, its quality, fitness for purpose or safety, other than those set out in this contract.
(c) Unless we have acted in bad faith or negligently, the National Energy Retail Law excludes our liability for any loss or damage you suffer as a result of the total or partial failure to supply energy to your premises, which includes any loss or damage you suffer as a result of the defective supply of energy.
Product Liability Claims As soon as it becomes aware, each party will give the other prompt written notice of any defect or alleged defect in a Product, any injury alleged to have occurred as a result of the use or application of a Product, and any circumstances that may give rise to litigation or recall of a Product or regulatory action that may affect the sale or manufacture of a Product, specifying, to the extent the party has such information, the time, place and circumstances thereof and the names and addresses of the persons involved. Each party will also furnish promptly to the other copies of all papers received in respect of any claim, action or suit arising out of such alleged defect, injury or regulatory action.
Seller’s Liability SELLER’s liability with respect to the Product sold to END USER shall be limited to the warranty provided herein. SELLER shall not be subject to any other obligations or liabilities, whether arising out of breach of contract, warranty, tort (including negligence and strict liability) or other theories of law, with respect to products sold or services rendered by seller, or any undertaking, acts or omissions relating thereto. Without limiting the foregoing, SELLER specifically disclaims any liability for property or personal injury damages, penalties, special or punitive damages, damages for lost profits or revenues, services, down time, shut down or slow down costs, or for any other types of economic loss, and for claims of END USER’s customers or any third party for any such damages. SELLER shall not be liable for and disclaims all consequential, incidental and contingent damages whatsoever.
