Delay Beyond City and Contractor Control Sample Clauses

Delay Beyond City and Contractor Control. The Contractor will not be held responsible for delays in performance of the Work caused by delay beyond the control of both City and Contractor, such as by strikes, lockouts, or labor disturbances that are not within the control of the contractor to resolve, lack or failure of transportation, or acts of other government entities. This provision will not apply where the delay would not have affected the Work but for a previous delay in the prosecution of the Work attributed to the Contractor, as set forth in Section 7.3. The City will not be liable to the Contractor, any subcontractor, or other entity engaged in the performance of the Work, any supplier, or any other person or organization, or to any surety or employee or agent of any of them, for damages arising out of or resulting from (i) delays beyond the control of the City and the Contractor including, but not limited to, fires, floods, epidemics, abnormal weather conditions, earthquakes and acts of God or acts or neglect by utility owners or other contractors performing other work, or (ii) delays caused by the City, its officials, officers, employees, agents, or volunteers, or delays caused by the Construction Manager or the Architect or Engineer, which delays are reasonable under the circumstances involved and/or are within the contemplation of the City and the Contractor. An extension of the Time for Performance in an amount equal to the time loss due to such delay(s) will be the Contractor's sole and exclusive remedy for such delay(s).
Sample 1
AutoNDA by SimpleDocs

Related to Delay Beyond City and Contractor Control

  • Causes Beyond Control Neither party of this contract shall be held responsible for delay or default caused by fire, riot, acts of God, sovereign, public enemy, and/or war which is beyond that party's control. The STATE may terminate this contract upon written notice after determining such delay or default will reasonably prevent successful performance of the contract. In the event a cause or causes beyond control impact this contract, the STATE may grant a reasonable extension of time and shall not additionally compensate the PURCHASER.

  • Erosion Prevention and Control Purchaser’s Operations shall be conducted reasonably to minimize soil erosion. Equipment shall not be operated when ground conditions are such that excessive damage will result. Purchaser shall adjust the kinds and intensity of erosion control work done to ground and weather condi- tions and the need for controlling runoff. Erosion control work shall be kept current immediately preceding ex- pected seasonal periods of precipitation or runoff. If Purchaser fails to do seasonal erosion control work prior to any seasonal period of precipitation or runoff, Forest Service may temporarily assume responsibility for the work and any unencumbered deposits hereunder may be used by Forest Service to do the work. If needed for such work, Purchaser shall make additional deposits on request by Forest Service. Any money deposited or used for this purpose shall be treated as cooperative deposits under B4.218.

  • Obligations Beyond Contract Term The Contract shall remain in full force and effect to the end of the specified term or until terminated or canceled pursuant to the Contract. All obligations of the Contractor incurred or existing under the Contract as of the date of expiration, termination or cancellation will survive the termination, expiration or conclusion of the Contract.

  • 190 Contract Complete This contract is the final expression of the Parties' agreement. There are no understandings, agreements, or representations, expressed or implied, which are not specified in this contract.

  • Musculoskeletal Injury Prevention and Control (a) The Hospital in consultation with the Joint Health and Safety Committee (JHSC) shall develop, establish and put into effect, musculoskeletal prevention and control measures, procedures, practices and training for the health and safety of employees.

  • CONTRACTOR STAFF WITHIN AUTHORIZED USER AGREEMENT The provisions of this section shall apply unless otherwise agreed in the Authorized User Agreement. All employees of the Contractor, or of its Subcontractors, who shall perform under an Authorized User Agreement, shall possess the necessary qualifications, training, licenses, and permits as may be required within the jurisdiction where the Services specified are to be provided or performed, and shall be legally entitled to work in such jurisdiction. All Business Entities that perform Services under the Contract on behalf of Contractor shall, in performing the Services, comply with all applicable Federal, State, and local laws concerning employment in the United States. Staffing Changes within Authorized User Agreement

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • PROJECT REPRESENTATION BEYOND BASIC SERVICES 1.2.1. The State may at its option secure the services of a person or persons known as a Clerk-of-the-Works, referred to herein as a "Clerk". The Clerk(s) shall, for all purposes of this Agreement, report and be solely responsible to the State. The State may at any time dismiss the Clerk(s) for cause or convenience; however, any such action shall not affect the State's and ARCHITECT/ENGINEER'S obligations under this Agreement. In such event, the State shall use their best efforts to secure the services of a Clerk or Clerks under this paragraph as soon as is practicable if the State deems it necessary.

  • ADDITIONAL CONTRACTOR TERMS AND CONDITIONS WITHIN AN AUTHORIZED USER AGREEMENT Additional Contractor Terms and Conditions may become part of an Authorized User Agreement in accordance with Section 28 of Appendix B. EMPLOYEE INFORMATION REQUIRED TO BE REPORTED BY CERTAIN CONSULTANT CONTRACTORS AND SERVICE CONTRACTORS Civil Service Law § 97 and State Finance Law § 163 establish reporting requirements for maintaining certain information concerning Contract Employees working under State Agency service and consulting Contracts. State Agency consultant Contracts are defined as “Contracts entered into by a state Agency for analysis, evaluation, research, training, data processing, computer programming, engineering, environmental health and mental health services, accounting, auditing, paralegal, legal, or similar services” (“covered consultant Contract” or “covered consultant services”). The information must be provided to the state Agency awarding such Contracts, OSC, DOB and CS. To meet these requirements, the Contractor agrees to complete:

  • Dental Services - Accidental Injury (Emergency Emergency room - When services are due to accidental injury to sound natural teeth. 0% - After deductible The level of coverage is the same as network provider. In a physician’s/dentist’s office - When services are due to accidental injury to sound natural teeth. 0% - After deductible 40% - After deductible Dental Services - Outpatient Services connected to dental care when performed in an outpatient facility * 0% - After deductible 40% - After deductible Covered Benefits - See Covered Healthcare Services for additional benefit limits and details. Network Providers Non-network Providers (*) Preauthorization may be required for this service. Please see Preauthorization in Section 5 for more information. You Pay You Pay Dental Care (Pediatric) - for members under age 19 See Dental Services in Section 3 for benefit limits and details. These services only apply to an enrolled member under the age of 19. Oral evaluations 0% - After deductible 0% - After deductible X-rays 0% - After deductible 0% - After deductible Cleanings (prophylaxis) 0% - After deductible 0% - After deductible Fluoride treatments 0% - After deductible 0% - After deductible Sealants 0% - After deductible 0% - After deductible Space Maintainers 0% - After deductible 0% - After deductible Palliative treatment 50% - After deductible 50% - After deductible Fillings 50% - After deductible 50% - After deductible Simple extractions 50% - After deductible 50% - After deductible Denture repairs and relines/rebasing 50% - After deductible 50% - After deductible Crowns & onlays 50% - After deductible 50% - After deductible Therapeutic Pulpotomies 50% - After deductible 50% - After deductible Root canal therapy 50% - After deductible 50% - After deductible Non-surgical periodontal services 50% - After deductible 50% - After deductible Surgical periodontal services 50% - After deductible 50% - After deductible Periodontal maintenance 50% - After deductible 50% - After deductible Fixed bridges and dentures 50% - After deductible 50% - After deductible Implants 50% - After deductible 50% - After deductible Oral surgery services 50% - After deductible 50% - After deductible General anesthesia or IV sedation - dental office 50% - After deductible 50% - After deductible Biopsies 50% - After deductible 50% - After deductible Occlusal (night) guards 50% - After deductible 50% - After deductible Orthodontic services (braces) - when medically necessary. 50% - After deductible 50% - After deductible Dialysis Services Inpatient/outpatient/in your home 0% - After deductible 40% - After deductible Durable Medical Equipment (DME), Medical Supplies, Diabetic Supplies, Prosthetic Devices, and Enteral Formula or Food, Hair Prosthetics Outpatient durable medical equipment* - Must be provided by a licensed medical supply provider. 20% - After deductible 40% - After deductible Outpatient medical supplies* - Must be provided by a licensed medical supply provider. 20% - After deductible 40% - After deductible Outpatient diabetic supplies/equipment purchased at licensed medical supply provider (other than a pharmacy). See the Summary of Pharmacy Benefits for supplies purchased at a pharmacy. 20% - After deductible 40% - After deductible Outpatient prosthesis* - Must be provided by a licensed medical supply provider. 20% - After deductible 40% - After deductible Enteral formula delivered through a feeding tube. Must be sole source of nutrition. 20% - After deductible 40% - After deductible Enteral formula or food taken orally * 20% - After deductible The level of coverage is the same as network provider. Hair prosthesis (wigs) - The benefit limit is $350 per hair prosthesis (wig) when worn for hair loss suffered as a result of cancer treatment. 20% - After deductible The level of coverage is the same as network provider.

Time is Money Join Law Insider Premium to draft better contracts faster.