Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.
Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.
Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
Extension of Defects Liability Period The Defects Liability Period shall be deemed to be extended till the identified Defects under Clause 17.2 have been remedied or rectified.
EXTENSION OF USE The Contract may be extended to additional States or governmental jurisdictions upon mutual written agreement between New York State (the lead contracting State) and the Contractor. Political subdivisions and other authorized entities within each participating State or governmental jurisdiction may also participate in the Contract if such State normally allows participation by such entities. New York State reserves the right to negotiate additional minimum NYS Vehicle Discounts based on any increased volume generated by such extensions.
Amendments; Renewal Any amendments, consents to or waivers of the terms of this Contract must be in writing and signed by both parties. The parties may renew this Contract by their signed, written instrument.
