DELIVERIES AND PERFORMANCE. CLAUSES INCORPORATED BY REFERENCE FAR SOURCE TITLE, DATE & Contract Order REFERENCE F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) (Reference 11.404) Complete as follows:
DELIVERIES AND PERFORMANCE. F.1 52.242-15 Stop-Work Order. (AUG 1989) – Alternate I (APR 1984) F.2 GSFC 52.217-92 Period of Performance (JAN 2014) The period of performance of this contract shall be for a period of 2 years from the contract effective date of TBD. (End of clause) F.3 GSFC 52.237-92 Place of Performance - Services. (NOV 2013) The services to be performed under this contract shall be performed at the following location(s):
DELIVERIES AND PERFORMANCE. F.1 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998) This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): xxx.xxxxx.xxx/xxx/. (End of clause) FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES NUMBER TITLE DATE 52.211-17 DELIVERY OF EXCESS QUANTITIES SEPT 1989 52.242-15 STOP-WORK ORDER AUG 1989 52.242-15 STOP WORK ORDER – ALTERNATE I (Apr 1984) AUG 1989 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 52.247-35 F.O.B. DESTINATION, WITHIN CONSIGNEE’S PREMISES AUG 1984 52.249-14 EXCUSABLE DELAYS APR 1984 F.2 CAR 1352.270-70 PERIOD OF PERFORMANCE (APR 2010)
DELIVERIES AND PERFORMANCE. F.1 CLAUSES INCORPORATED BY REFERENCE F-1 F.2 PERIOD OF PERFORMANCE F-1 F.3 LOCATION(S) F-1 F.4 UNAVAILABILITY F-1 F.5 CONTRACTOR EVALUATIONS F-1 SECTION G - CONTRACT ADMINISTRATION DATA G.1 MOBILE SHOWER FACILITY – MILEAGE G-1 G.2 MOBILE SHOWER FACILITY UNIT – DAILY USAGE RATE G-1 G.3 INTERMITTENT USE OF CONTRACTORS POTABLE WATER VEHICLE G-2 G.4 RELOCATION FEE G-3 G.5 MISCELLANEOUS CHARGES AND CREDITS G-3 G.6 PAYMENT PROCEDURES G-3
DELIVERIES AND PERFORMANCE. F0001 F1.37 DETERMINATION OF QUANTITY FOR AVIATOR’S BREATHING OXYGEN AND LIQUID NITROGEN (AEROSPACE ENERGY) (DLA ENERGY MAY 2007)
DELIVERIES AND PERFORMANCE. F.1 FAR 52.252-2
DELIVERIES AND PERFORMANCE. F-1 52.252-2 CONTRACT CLAUSES INCORPORATED BY REFERENCE (FEB 1998) THIS CONTRACT INCORPORATES THE FOLLOWING REQUIRED CONTRACT CLAUSES BY REFERENCE, WITH THE SAME FORCE AND EFFECT AS IF THEY WERE GIVEN IN FULL TEXT. UPON REQUEST, THE CONTRACTING OFFICER WILL MAKE THEIR FULL TEXT AVAILABLE. FAR NUMBER TITLE DATE 52.242-15 Stop Work Order (APR 1984) AUG 1989 52.242-17 Government Delay of Work APR 1984 52.247-29 F.O.B. Origin JUN 1988 52.247-34 F.O.B. Destination NOV 1991 DFAR NUMBER TITLE DATE 252.242-7003 Application for U.S. Government Shipping Documentation/Instructions DEC 1991 F-2 Delivery Terms Deliveries shall be made on F.O.B. terms as indicated herein: Interim Small Unit Remot Scouting System Contract No.: M67854-04-D1011 MARCORSYSCOM
DELIVERIES AND PERFORMANCE. F0001 F1.11 DLA INTERNET BID BOARD SYSTEM (DIBBS) (DLA ENERGY) (APR 2014) THIS CONTRACT TEXT ONLY APPLIES TO DLA FUNDED LINE ITEMS.
DELIVERIES AND PERFORMANCE. F-0001 F1.36 DETERMINATION OF QUANTITY (PROPELLANTS, CRYOGENICS AND GASES) (AEROSPACE ENERGY) (DLA ENERGY APR 2006)
DELIVERIES AND PERFORMANCE. IS . SECTION G - CONTRACT ADMINISTRATION DATA 18 G.1 PROJECT OFFICER AUTHORITY (MAR 1987). ALTERNATE II (MAR 1987) 18 G.2 REMITTANCE ADDRESS (MAR 1987)
