DELIVERY, RISK, PACKAGES, ETC Sample Clauses

DELIVERY, RISK, PACKAGES, ETC. 1. Unless otherwise provided, all goods are to be supplied only against the official form of order issued by the Municipality. 2. The risk in all goods purchased by the Municipality under the contract shall remain with the contractor until such goods shall have been duly delivered. 3. Bidders shall quote a unit price which shall include delivery to specified delivery point within the eThekwini Municipal area. 4. Bidders shall clearly state the period within which delivery will be made after receipt of the official order, as this may be material in the adjudication of the Bid.
AutoNDA by SimpleDocs

Related to DELIVERY, RISK, PACKAGES, ETC

  • Delivery; Risk of Loss Deliveries must be made both in quantities and at times specified on the face of the Purchase Order or in Buyer's schedules and time is of the essence. Buyer’s delivery schedules are an integral part of the Purchase Order, are governed by these terms and conditions and are not independent contracts. ▪ Buyer will not be required to make payment for goods delivered to Buyer that are in excess of quantities specified in Buyer's delivery schedule on the Purchase Order or in written releases issued by Buyer. Buyer may reject any deliveries made after or before the specified delivery date. Seller will bear all costs and damages incurred by Buyer due to late or early delivery. ▪ If Seller fails to meet the agreed upon delivery requirements for reasons other than those specified in paragraph 13 below, and Buyer requires a more expeditious method of transportation for the goods than the transportation method originally specified, Seller shall ship the goods as expeditiously as possible at Seller's expense and invoice Buyer for the amount, if any, that Buyer would have paid for normal shipment. ▪ Unless provided otherwise in the Purchase Order, all goods are sold DAP. Seller shall be responsible for and bear the risk of any loss or damage to the goods until received by the Buyer.

  • ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.

  • Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas. A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below. 1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

  • Project Delivery Order Procedures Status of TIPS Members as Related to This Agreement

  • DELIVERY, STORAGE, AND HANDLING The Contractor shall be responsible to inspect all components on delivery to ensure that no damage occurred during shipping or handling for furnish and installation projects. For equipment only purchases, the ordering entity shall be responsible to inspect all components on delivery. Materials must be stored in original undamaged packaging in such a manner to ensure proper ventilation and drainage, and to protect against damage, weather, vandalism, and theft until ready for installation.

  • DELIVERY INSTRUCTIONS In the event of a Failed Remarketing, Notes which are in physical form should be delivered to the person(s) set forth below and mailed to the address set forth below. Name(s) Address In the event of a Failed Remarketing, Notes which are in book-entry form should be credited to the account at The Depository Trust Company to the person(s) set forth below. DTC Account Number: Name of Account Party: U.S. Bank National Association, as Custodial Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Notes Due 2042 of Xxxxxxx Controls, Inc. (the “Company”). The undersigned hereby notifies you in accordance with Section 5.03(d) of the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Agreement”), among the Company and you, as Collateral Agent, Custodial Agent and Securities Intermediary, and U.S. Bank National Association, as Purchase Contract Agent and as attorney-in-fact for the holders of Corporate Units and Treasury Units from time to time, that the undersigned elects to withdraw the $ aggregate principal amount of Separate Notes delivered to you for Remarketing pursuant to Section 5.03 of the Agreement. The undersigned hereby instructs you to return such Separate Notes to the undersigned in accordance with the undersigned’s instructions. With this notice, the Undersigned hereby agrees to be bound by the terms and conditions of Section 5.03(d) of the Agreement. Capitalized terms used herein but not defined shall have the meaning set forth in the Agreement. Date: By: Name: Title: Signature Guarantee: Name Address U.S. Bank National Association, as Purchase Contract Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”) The undersigned Holder hereby irrevocably notifies you in accordance with Section 5.03(b)(iii) of the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Purchase Contract and Pledge Agreement”; unless otherwise defined herein, terms defined in the Purchase Contract and Pledge Agreement are used herein as defined therein), among the Company and you, as Purchase Contract Agent, as attorney-in-fact for the Holders of the Corporate Units, Collateral Agent, Custodial Agent and Securities Intermediary, that such Holder has elected to pay to the Securities Intermediary for deposit in the Collateral Account, on or prior to 4:00 p.m. (New York City time) on the Business Day immediately preceding the Purchase Contract Settlement Date (in lawful money of the United States by certified or cashiers check or wire transfer, in immediately available funds payable to or upon the order of the Securities Intermediary), $ as the Purchase Price for the shares of Common Stock issuable to such Holder by the Company with respect to Purchase Contracts on the Purchase Contract Settlement Date. The undersigned Holder hereby instructs you to notify promptly the Collateral Agent of the undersigned Holders’ election to settle the Purchase Contracts related to such Holder’s Corporate Units with separate cash. Date: Signature: Signature Guarantee: Please print name and address of Registered Holder: NOTICE FROM PURCHASE CONTRACT AGENT TO COLLATERAL AGENT (Settlement with Separate Cash) U.S. Bank National Association, as Collateral Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”) Please refer to the Purchase Contract and Pledge Agreement, dated as of March 16, 2009 (the “Agreement”), among the Company, you, as Collateral Agent, as Securities Intermediary and as Custodial Agent, and the undersigned, as Purchase Contract Agent and as attorney-in-fact for the Holders of Corporate Units from time to time. Capitalized terms used herein but not defined shall have the meaning set forth in the Agreement. We hereby notify you in accordance with Section 5.03(b)(iii) of the Agreement that the Holder of Corporate Units named below (the “Holder”) has elected to settle the Purchase Contracts related to its Pledged Applicable Ownership Interests in Notes with $ of separate cash prior to 11:00 a.m. (New York City time) on the second Business Day immediately preceding the Purchase Contract Settlement Date (in lawful money of the United States by certified or cashiers check or wire transfer, in immediately available funds payable to or upon the order of the Securities Intermediary) and has delivered to the undersigned a notice to that effect. We hereby request that you, upon confirmation that the Purchase Price has been paid by the Holder to the Securities Intermediary in accordance with Section 5.03(b)(iii) of the Agreement in lieu of exercise of such Holder’s Put Right, give us notice of the receipt of such payment and (A) promptly invest the separate cash received in Permitted Investments consistent with the instructions of the Company as provided in Section 5.03(a)(v) of the Agreement with respect to Cash Settlement, (B) promptly release from the Pledge the Notes underlying the Applicable Ownership Interest in Notes related to the Corporate Units as to which such Holder has paid such separate cash; and (C) promptly Transfer all such Notes to us for distribution to such Holder, in each case free and clear of the Pledge created by the Agreement. Date: ________________________, U.S. Bank National Association, as Purchase Contract Agent and as attorney-in-fact of the Holders from time to time of the Units By: Name: Title: Authorized Signatory Please print name and address of Holder electing to settle with separate cash: Name: Social Security or other Taxpayer Identification Number, if any Address: NOTICE OF SETTLEMENT WITH SEPARATE CASH FROM SECURITIES INTERMEDIARY TO PURCHASE CONTRACT AGENT (Settlement with Separate Cash) U.S. Bank National Association, as Purchase Contract Agent 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Re: Corporate Units of Xxxxxxx Controls, Inc. (the “Company”) Please refer to the Purchase Contract and Pledge Agreement dated as of March 16, 2009 (the “Agreement”), by and among you, the Company, and U.S. Bank National Association, as Collateral Agent, Custodial Agent and Securities Intermediary. Unless otherwise defined herein, terms defined in the Agreement are used herein as defined therein. In accordance with Section 5.03(b)(iii) of the Agreement, we hereby notify you that as of 4:00 p.m. (New York City time) on the Business Day immediately preceding March 31, 2012 (the “Purchase Contract Settlement Date”), (i) we have received from $ in immediately available funds paid in an aggregate amount equal to the Purchase Price due to the Company on the Purchase Contract Settlement Date with respect to Corporate Units and (ii) based on the funds received set forth in clause (i) above, an aggregate principal amount of $ of Notes underlying related Pledged Applicable Ownership Interests in Notes are to be released from the Pledge and Transferred to you. U.S. Bank National Association, as Securities Intermediary Dated: By: [______________________] U.S. Bank National Association 000 Xxxx Xxxxxx Xxx Xxxx, Xxx Xxxx 00000 Tel: (000) 000-0000 Fax: (000) 000-0000 Attention: Xxxxxxx X. Xxxxxxx, Vice President Ladies and Gentlemen: This Agreement is dated as of [•] (the “Agreement”) by and among Xxxxxxx Controls, Inc., a Wisconsin corporation (the “Company”), [_______________________], as the reset agent and the remarketing agent (the “Remarketing Agent”), and U.S. Bank National Association, a national banking association, not individually but solely as Purchase Contract Agent (the “Purchase Contract Agent”) and as attorney-in-fact of the holders of Purchase Contracts (as defined in the Purchase Contract and Pledge Agreement referred to below).

  • Delivery Point The delivery point is the point of delivery of the Power Product to the CAISO Controlled Grid (the “Delivery Point”). Seller shall provide and convey to Buyer the Power Product from the Generating Facility at the Delivery Point. Title to and risk of loss related to the Power Product transfer from Seller to Buyer at the Delivery Point.

  • Delivery and Risk of Loss Unless otherwise provided for in advance, all shipments will be made F.O.B. Seller's facility, and upon Seller's delivery of a shipment to the carrier, Buyer shall assume the risk of any loss or damage to the shipment thereafter. Delivery and/or completion dates furnished by Seller represent the best estimates of the time required to make shipment or complete services, and Seller does not guarantee delivery or completion by a particular date unless otherwise stated herein or in any schedule or addendum attached hereto. If a delivery date for products is guaranteed herein, (a) Seller’s unexcused delay in delivering one installment to the carrier at Seller’s facility shall permit Buyer to cancel only that installment, and acceptance by Buyer or the act of taking possession of products by the carrier shall constitute a bar to any claim of late delivery with respect to such products and (b) Buyer shall not be excused from performance if for any reason, the carrier does not pick up products on the date specified for shipping, and Seller may dispose of any products which the carrier does not pick-up within five (5) days of the date agreed for delivery to the carrier at Seller’s facility if Buyer refuses acceptance based on such delay, in which case Seller may cancel the order without notice to Buyer and Buyer shall be responsible for a 25% restocking fee as to the products ordered. In any such event, Seller shall have no duty to mitigate its damages. Seller may deliver any products subject to an order to the carrier at its facility in part and in such event, Buyer shall be responsible for payment for that part of the order received by the carrier, and Seller shall only be responsible for that portion of an order which Seller is required to but does not deliver.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!