Delivery Terms All Material prices are quoted on the basis of Free Carrier (FCA) delivery terms, without regard to the place from which such Material is shipped. The term “Free Carrier (FCA)” is as defined by publication n° 560 of the International Chamber of Commerce, published in January 2000.
Delivery Location The Aircraft shall be located at the agreed Delivery Location;
Delivery Point Once Manufacture of the Products has been completed, Contractor shall be responsible for delivering the Finished Goods FCA, (as defined in Incoterms (2000) published by the International Chamber of Commerce) and to a freight forwarder specified by Company in its Order, or otherwise approved by Company. “Delivery Point” as used in this Agreement shall mean the specific time and location that the Product is delivered to the shipper specified on the Order.
Contract Terms To Be Exclusive This written agreement contains the sole and entire agreement between the parties, and supersedes any and all other agreements between them. The parties acknowledge and agree that neither of them has made any representation with respect to the subject matter of this agreement or any representations inducing the execution and delivery hereof except such representations as are specifically set forth herein, and each party acknowledges that he or it has relied on his or its own judgment in entering into the agreement. The parties further acknowledge that any statements or representations that may have heretofore been made by either of them to the other are void and of no effect and that neither of them has relied thereon in connection with his or its dealings with the other.
Delivery Points The measurement of and tests for quality of Shipper's Gas redelivered at the Delivery Points shall be governed by and determined in accordance with the requirements of the receiving pipeline at each Delivery Point.
Purchase Order “Purchase Order” shall have the meaning set forth in Section 7.1.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Manufacturing Services Jabil will manufacture the Product in accordance with the Specifications and any applicable Build Schedules. Jabil will reply to each proposed Build Schedule that is submitted in accordance with the terms of this Agreement by notifying Company of its acceptance or rejection within three (3) business days of receipt of any proposed Build Schedule. In the event of Jabil’s rejection of a proposed Build Schedule, Jabil’s notice of rejection will specify the basis for such rejection. When requested by Company, and subject to appropriate fee and cost adjustments, Jabil will provide Additional Services for existing or future Product manufactured by Jabil. Company shall be solely responsible for the sufficiency and adequacy of the Specifications [***].
Delivery Schedule The scheduled months of delivery of the Aircraft are listed in the attached Table 1. Exhibit B describes certain responsibilities for both Customer and Boeing in order to accomplish the delivery of the Aircraft.
Forecasts and Purchase Orders On or before the twelfth (12th) day of each month, beginning on January 12, 2022, Indivior shall furnish to Curia a written twelve (12) month rolling forecast of the quantities of Product that Indivior intends to order from Curia during such period ("Rolling Forecast"). The first six (6) months of such Rolling Forecast shall constitute a firm and binding commitment to order quantities of Product specified therein ("Firm Period Forecast"), and the following six (6) months of the Rolling Forecast shall be non-binding, good faith estimates. Each month of the Rolling Forecast shall begin on the twelfth (12th) of the calendar month in which such Rolling Forecast is submitted and end on the eleventh (11th) day of the following calendar month. With exception to the Firm Period Forecast, Curia reserves the right to reject any Rolling Forecast that does not align with the physical Processing capabilities of the Facility(ies) and the parties shall work in good faith to adjust the Rolling Forecast based on available resources, Facility capacity and other relevant factors. Indivior shall have the right to request an increase of the Firm Period Forecast to include additional units of Product. Curia may, in its sole discretion, supply such additional quantities, subject to Curia's other supply commitments and manufacturing capacity. In the event Curia agrees to supply such additional quantities, Indivior shall submit a Purchase Order for such additional quantities, with the required lead times as specified below. In no event shall Curia's inability to fulfill Purchase Orders for quantities in excess of the Firm Period Forecast be deemed a breach of this Agreement, nor relieve Indivior of its obligations under this Agreement. Indivior shall submit with each Rolling Forecast, a non-cancelable Purchase Order for the Firm Period Forecast (or such portion of the Firm Period Forecast not covered by previously submitted Purchase Orders). Indivior may alternatively submit Purchase Orders for certain portions of the Firm Period Forecast subsequent to the submission of the Rolling Forecast, provided the Purchase Orders provide the required lead time for Processing as set forth below. Curia shall notify Indivior of acceptance of the Rolling Forecast and any Purchase Order within seven (7) business days of receipt. Curia shall be deemed to have accepted Purchase Orders which it does not acknowledge within seven (7) business days of receipt. Curia shall have the right to reject Rolling Forecasts and Purchase Orders that are inconsistent with this Agreement. Each Purchase Order shall specify the quantity of Product being ordered, and the desired delivery date. Upon mutual agreement in writing for additional quantities of Product beyond the Firm Period Forecast, including projected delivery date(s), Indivior shall issue the applicable Purchase Order to be accepted by Curia as described above. Once placed, all Purchase Orders for Product shall be non-cancelable. No different or additional terms or conditions set forth in any Purchase Order shall modify in any way the terms and conditions of this Agreement, and in the event of a conflict between terms in any Purchase Order and this Agreement, the terms of this Agreement shall control. All Purchase Orders submitted in accordance with the terms of this Agreement shall be effective and binding on the parties upon acceptance by Curia. Except as otherwise provided herein, neither party shall have the right or power to refuse, reduce, or otherwise modify their obligations under any Purchase Order; however, Purchase Orders may be amended (i) upon written mutual agreement regarding such modification that is signed by both parties; or (ii) as otherwise provided in this Section 4.3 or Section 4.4.
