STUDENT’S RIGHT TO CANCEL You have the right to cancel or withdraw and receive a refund of 100% of the amount paid for institutional charges, less the STRF of $0.00, and a reasonable deposit or application fee not to exceed $250, through attendance at the first class session, or the seventh day after enrollment, whichever is later, if notice of cancellation is received on or before the right to cancel date. See table below. First Term of Enrollment 2020-2021 Academic Year Application Deadline Classes Begin Right to Cancel Date Fall Term 2020 Sept 1, 2020 Sept 8, 2020 Sept 15, 2020 Spring Term 2021 Jan 14, 2021 Jan 19, 2021 Jan 26, 2021 Summer Term 2021 June 1, 2021 June 7, 2021 June 14, 2021 To cancel, students must submit a written and signed notice of Withdrawal Form to the Registrar's Office by the right to cancel date above. The Withdrawal Form can be downloaded from xxx.xxxxxxxxxxxxxxxx.xxx/xxxxxxxxx/ student-forms. Students are not required to purchase books, supplies or equipment through Cambridge College, and the College does not offer student housing or transportation. Therefore these expenses cannot be refunded by the College. REFUNDS & REPAYMENT Students who withdraw from Cambridge College after having paid the current term charges or receiving financial aid are subject to the following refund and repayment policies. Federal guidelines mandate that tuition, fees, and other related charges are prorated based upon each student’s enroll- ment status. Tuition and fees may be refunded. No other charges are refundable. REFUNDS & REPAYMENT—STUDENTS RECEIVING TITLE IV FINANCIAL AID Exit Counseling. All borrowers of federal student loans must complete federally mandated exit counseling when gradu- ating or dropping to less than half-time enrollment status. Exit counseling prepares students for repayment. Students must do the exit counseling in its entirety, with complete and correct information; otherwise the degree, diploma, and official transcripts will be withheld. To complete the exit interview online, go to xxx.xxxxxxxxxxxx.xxx, and click on Exit Counseling. Repayment of Federal Funds. Students receiving federal financial aid, who withdraw from the College or stop attending all classes during a term before more than 60% of the term has elapsed, are subject to specific federal regulations. The amount of Title IV aid that you must repay is determined by the federal formula for return of Title IV funds as speci- fied in Section 484B of the Higher Education Act. The amount of Title IV aid that you earned during the term before you withdrew is calculated by multiplying the total aid for which you qualified by the percentage of time in the term that you were enrolled (college work-study not included). Your disbursement or repayment owed: • If less aid was disbursed to you than you earned, you may receive a late disbursement for the difference. • If more aid was disbursed to you than you earned, you will be billed for the amount you owe to the Title IV programs and any amount due to the College resulting from the return of Title IV funds used to cover College charges. Cambridge College will return the unearned aid to Title IV programs as specified by law. Students who have received federal student financial aid funds are entitled to a refund of any moneys not paid from federal student financial aid program funds (see below).
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
STATE'S RIGHT TO CARRY OUT THE WORK 3.4.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within seven days after receipt of written notice from the State to commence and continue correction of such default or neglect with diligence and promptness, the State may, after seven days following receipt by the Contractor of an additional written notice and without prejudice to any other remedy he may have, make good such deficiencies. In such case an appropriate Change Order shall be issued deducting from the payments then or thereafter due the Contractor the cost of correcting such deficiencies, including compensation for the Architect's and the State’s additional services made necessary by such default, neglect or failure. Such action by the State and the amount charged to the Contractor are both subject to review by the Architect under Paragraph 2.2.14 of these General Conditions. If the payments then or thereafter due the Contractor are not sufficient to cover the amounts paid by the State to make good such deficiencies, then the Contractor shall pay the difference to the Owner.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.1.5. There is no legal limitation on the Owner’s right to make changes such as may be, in the Owner’s sole discretion, useful or desirable to the Project.
No Right to Cancel You do not have the right to cancel your subscription or change your mind. Once you sign this Investment Agreement, you are obligated to purchase the Note, no matter what, even if the ORering is over-subscribed and the amount of your Note is reduced.
DISCHARGE OR SUSPENSION The Employer shall not discharge nor suspend any employee without just cause, but in respect to discharge or suspension shall give at least one (1) warning notice of a complaint against such employee to the employee, in writing, and a copy of the same to the Union, except that no warning notice need be given to an employee before he/she is discharged if the cause of such discharge is dishonesty, drinking alcoholic beverages or being under the influence of drugs or in illegal possession of drugs during the workday (including meal period) or drunkenness, recklessness resulting in serious accident while on duty, or the carrying of unauthorized passengers while on the job or offenses of equal seriousness. Except for serious accidents, a driver will not be removed from the payroll during an investigation of an accident. The driver can be assigned to non-driving work during this period. Before disciplinary action is taken, a meeting shall be held with the employee and the employee shall have the right to choose a Xxxxxxx who is readily available and on the premises. In the case of discharge for any offense other than the above mentioned, including suspension, the disciplinary action will be held in abeyance for two (2) weeks to give the Local Union the opportunity to intervene prior to the action being taken. The warning notice, suspension or discharge as herein provided shall not remain in effect for a period of more than nine (9) months from the date of said warning notice, suspension or discharge. Any disciplinary action must be by proper written notice to the employee and the Union affected. Disciplinary letters must be issued by the Company within ten (10) working days after the incident. Any employee may request an investigation as to his/her discharge or suspension. Should such investigation prove that an injustice has been done to an employee, he/she shall be reinstated. The C.P.A.P.G.C. or the impartial arbitrator shall have the authority to order full, partial or no compensation for time lost. Appeal from discharge or suspension must be taken within ten (10) days by written notice and a decision reached within thirty (30) days from the date of suspension or discharge. An employee shall be given a copy of any Company form or document signed by the employee if requested. The Company will not use absenteeism or accidents in conjunction with any other disciplinary action.
STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:
