Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Obligation to Suspend Distribution Upon receipt of any notice from the Company of the happening of any event of the kind described in Section 3.1.4(iv), or, in the case of a resale registration on Form S-3 pursuant to Section 2.3 hereof, upon any suspension by the Company, pursuant to a written xxxxxxx xxxxxxx compliance program adopted by the Company’s Board of Directors, of the ability of all “insiders” covered by such program to transact in the Company’s securities because of the existence of material non-public information, each holder of Registrable Securities included in any registration shall immediately discontinue disposition of such Registrable Securities pursuant to the Registration Statement covering such Registrable Securities until such holder receives the supplemented or amended prospectus contemplated by Section 3.1.4(iv) or the restriction on the ability of “insiders” to transact in the Company’s securities is removed, as applicable, and, if so directed by the Company, each such holder will deliver to the Company all copies, other than permanent file copies then in such holder’s possession, of the most recent prospectus covering such Registrable Securities at the time of receipt of such notice.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
Right to Sublicense Company shall have the right to sublicense to any third party the rights conferred upon Company under this Agreement, subject to the following conditions:
2.4.1 Wistar shall have the right to approve in advance any Sublicensee if Company is not selling Licensed Product at the time of sublicensing negotiations, provided that such approval shall not be unreasonably withheld; and further provided, however, that such approval shall be deemed to have been given if Wistar does not object to the proposed Sublicensee within [**] ([**]) business days after Company notifies Wistar in writing of the name of such Sublicensee.
2.4.2 Any Sublicense shall be in writing, shall be consistent with all of the terms and conditions of this Agreement, and shall incorporate terms and conditions sufficient to enable Company to comply with this Agreement. Without limiting the foregoing, each Sublicense shall (i) provide that in the event Sublicensee brings a Patent Challenge against Wistar or assists another party in bringing a Patent Challenge against Wistar (except as required under a court order or subpoena or if legally compelled by an administrative agency) then Company may terminate the Sublicense, (ii) require Sublicensee to indemnify, hold harmless and defend Wistar and carry insurance under the same terms set forth in Article 6 below, and (iii)state that Wistar is an intended third party beneficiary of such Sublicense, including for the purpose of enforcing such termination, indemnification, and insurance provisions.
2.4.3 No Sublicensee shall be permitted to sublicense further any of its rights under any Sublicense. Each Sublicense shall contain an agreement and acknowledgment by the Sublicensee that such Sublicense and the Sublicensee are subject to the terms and conditions of the license granted to Company under this Agreement.
2.4.4 Notwithstanding any Sublicense, Company shall remain primarily liable to Wistar for all of Company’s duties and obligations contained in this Agreement, and any act or omission of a Sublicensee which would be a breach of this Agreement if performed by Company shall be deemed to be a breach by Company of this Agreement. Wistar Reference No. LIC15-35 Wistar/OncoCyte Certain information has been omitted under a request for confidential treatment, and the omitted information has been filed with the Commission. Confidential portions are marked [**].
2.4.5 If Wistar has a claim arising under this Agreement against a Sublicensee, Wistar may seek a remedy directly against Company and may, but is not required to, seek a remedy against the Sublicensee.
2.4.6 If Company becomes subject to a Bankruptcy Event, all payments then or thereafter due and owing to Company from its Sublicensees shall thereupon, and without any notice from Wistar to any such Sublicensee, become payable directly to Wistar for the account of Company; provided, however, that Wistar shall remit to Company any amount by which such payments exceed the amounts owed by Company to Wistar.
2.4.7 Company shall furnish Wistar with a fully executed copy of any Sublicense agreement within thirty (30) days after execution without redaction.
2.4.8 Any sublicense that is not in compliance with all of the provisions of this Section 2.4 shall be void.
