Design and Construction of Works Sample Clauses

Design and Construction of Works. (a) The Distributor will prepare the Construction Design which will be consistent with the Drawing (if provided). (b) Once the Construction Design has been completed, the Distributor will construct the Works on the least cost technically acceptable basis and in accordance with this Contract. (c) The Distributor may give the Customer a written notice requesting a variation to the Drawing (if provided) where: (i) there is a physical condition on the Land or its near surrounds which differs from the physical conditions which should reasonably have been anticipated by the Distributor; or (ii) land access rights such as a Registered Easement or Substation Lease, is required by the Distributor in respect of land that the Customer does not control, and Customer is unable to procure such land access rights in favour of the Distributor; or (iii) any change to any relevant law comes into effect on or after the Commencement Date. (d) If, within 10 Business Days of the Customer receiving the notice under clause 4.3(c), the Customer does not accept the requested variation to the Drawing, either party may give written notice to terminate this Contract immediately. The Distributor will stop carrying out the Works during the 10 Business Days unless the Customer gives the Distributor a written request to continue the Works. The Completion Date will be automatically extended by the same number of Business Days during which the Distributor stops carrying out the Works.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Design and Construction of Works. 6.1 MPDC will be responsible for the design and construction of that part of the Works that are located within the road reserve of Buckland Road for which MPDC is responsible as the territorial authority. 6.2 RSTL will be responsible for the design and construction of the Works that are located on any part of the Site which is owned, leased or occupied by RSTL or used by RSTL as part of the operation of the Hobbiton Movie Set and Tourism Activities. 6.3 The design and construction of all Works shall be undertaken by the Party responsible for those Works in accordance with the relevant NZ Transport Agency guidelines and manuals and Austroads design guidelines. 6.4 RSTL will be responsible for the cost of construction of the Works referred to in 6.1 and 6.2, excluding any works to lower Buckland Road.
Sample 1
Design and Construction of Works. (a) The Distributor will prepare the Construction Design which will be consistent with the Drawing (if provided). (b) Once the Construction Design has been completed, the Distributor will construct the Works on the least cost technically acceptable basis and in accordance with this Contract. (c) The Distributor may give the Customer a written notice requesting a variation to the Drawing (if provided) where: (i) there is a physical condition on the Land or its near surrounds which differs from the physical conditions which should reasonably have been anticipated by the Distributor; or (ii) land access rights (including a licence, Registered Easement, Substation Lease, Agreement for Lease or memorandum of Contract) are required by the Distributor in respect of land that the Customer does not control, and the Customer is unable to procure such land access rights in favour of the Distributor; or (iii) any change to any relevant law comes into effect on or after the Commencement Date. (d) If, within 10 Business Days of the Customer receiving the notice under clause 4.2(c), the Customer does not accept the requested variation to the Drawing, either party may give written notice to terminate this Contract immediately. The Distributor will stop carrying out the Works during the 10 Business Days unless the Customer gives the Distributor a written request to continue the Works. The Completion Date will be automatically extended by the same number of Business Days during which the Distributor stops carrying out the Works.
Sample 1

Related to Design and Construction of Works

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Definitions and Construction 1 1.1 Definitions.....................................................................................1 1.2

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Defined Terms Construction 1.01 Defined Terms 1.02 Construction 2.01 Loan Terms 2.02 Prepayment Premium 2.03 Exculpation 2.04 Application of Payments 2.05 Usury Savings 2.06 Floating Rate Mortgage - Third Party Cap Agreement 3.01 Security Instrument

  • New Construction If this contract is for a Property that is newly constructed and the new construction option is selected, coverage begins on day one (1) of month thirteen

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!