Detailed Plan Outline. The team will work with the city's project managers to create a detailed outline of the plan elements and document to ensure all needed topics and actions are present, and the document flow is most effective.
Detailed Plan Outline Sample Clauses
Related to Detailed Plan Outline
Detailed Description of Services / Statement of Work Describe fully the services that Contractor will provide, or add and attach Exhibit B to this Agreement.
Improvement Plan A written plan developed by the evaluator, utilized when a teacher received a Rating of Ineffective on his/her Evaluation or on any individual deficiency in the evaluation system.
Salary Schedule Progression Employees shall progress from step to step in salary grade on the basis of satisfactory job performance based upon established standards of performance. Seasonal employee's initial anniversary date shall be established after being in pay status for two thousand eighty (2,080) hours. Such date shall then be used for annual performance evaluation and step progression consideration. When an employee's anniversary date falls on any day from the first day of a pay week through Wednesday of the pay week, the employee's merit increase shall be effective as of the first day of the pay week within which the anniversary date falls. Otherwise, the merit increase shall be effective on the first day of the next pay week. Grievances arising from the denial of merit increases shall not be arbitrable under this Agreement but shall be processed as follows:
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Performance Improvement Plan timely and accurate completion of key actions due within the reporting period 100 percent The Supplier will design and develop an improvement plan and agree milestones and deliverables with the Authority
Approved Plan The Subrecipient agrees that it shall be committed to carry out pursuant to the Grantee’s specifications an Affirmative Action Program in keeping with the principles as provided in President’s Executive Order 11246 of September 24, 1966. The Grantee shall provide Affirmative Action guidelines to the Subrecipient to assist in the formulation of such program. The Subrecipient shall submit a plan for an Affirmative Action Program for approval prior to the award of funds.
General Project Description 2. Substation location.
Program Budget A) Contractor will expend funds received for operation of its program and services according to Contractor’s annual operating budget. The portions of said budget, which reflect services performed or money paid to Contractor pursuant to this Agreement shall be subject to the approval of the Human Services Agency. B) In the event Contractor determines a reasonable business necessity to transfer funding between personnel and operating expenses specified in the budget submitted to the Human Services Agency the following will apply: 1. Contractor will notify the Human Services Agency of transfers that in the aggregate are between ten percent (10%) and twenty percent (20%) of the maximum contract amount. 2. Contractor will further notify the Human Services Agency of transfers that in the aggregate equal or exceed twenty percent (20%) of the maximum contract amount. In the event the Director of the Human Services Agency or her designee determines said transfer of twenty percent (20%) or more is inconsistent with the goals and objectives of the County Alcohol and Drug Services, she may require a re-negotiation of the Agreement.
Improvement Plans a. An improvement plan is a clearly articulated assistance program for a teacher/counselor/SLP whose overall summative rating is ineffective.
