Detailed Requirements for the Goods Sample Clauses

Detailed Requirements for the Goods. The scope of this Supply Agreement shall include, but shall not be limited to: • design, manufacture, testing (including but not limited to factory testing) and supply of RTUs and associated equipment or related products (including but not limited to software and firmware), including assembly of all equipment either onto suitable gear plates or into a cubicle as required by RailCorp; • provision of all software & firmware necessary for the Goods to operate throughout their life; • delivery to a nominated RailCorp location or locations in the Sydney, Newcastle, Wollongong area of the rail network; • training of RailCorp’s maintenance personnel including the supply of training materials. The provision of training (and associated materials) shall be as required from time to time by RailCorp; • supply of RTU documentation which is sufficient for the purposes of operating and maintaining the Product over its design life per Appendix D1; and • provision of a perpetual and irrevocable licence (or licences) to use the Goods (including but not limited to any associated software, hardware or documentation) in relation to its intended purpose and to meet RailCorp’s broad business needs. The Supplier shall note that the configuration of the RTUs, including setting of parameters within the CPU to specify the number and addresses of I/O modules, RTU addresses etc. shall be done by RailCorp’s staff, using manuals and procedures provided by the Supplier. Also, the RTUs will be installed and commissioned by RailCorp in accordance with the Supplier’s written installation and commissioning instructions.
Sample 1
AutoNDA by SimpleDocs

Related to Detailed Requirements for the Goods

  • Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

  • Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).

  • Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.

  • Trunk Forecasting Requirements 14.2.1 Initial trunk forecast requirements. At least ninety (90) days before initiating interconnection in a LATA, Alltel shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.

  • Initial Trunk Forecast Requirements At least ninety (90) days before initiating interconnection in a LATA, Emergency shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.

  • Ongoing Trunk Forecast Requirements Where the Parties have already established interconnection in a LATA, Onvoy shall provide a new or revised traffic forecast that complies with the Frontier Interconnection Trunking Forecast Guide when Xxxxx develops plans or becomes aware of information that will materially affect the Parties’ interconnection in that LATA. Instances that require a new or revised forecast include, but are not limited to: (a) Onvoy plans to deploy a new switch; (b) Onvoy plans to implement a new POI or network architecture; (c) Onvoy plans to rearrange its network; (d) Onvoy plans to convert a One-Way Interconnection Trunk group to a Two-Way Interconnection Trunk group; (e) Onvoy plans to convert a Two-Way Interconnection Trunk group to a One-Way Interconnection Trunk group; or (f) Onvoy expects a significant change in interconnection traffic volume. In addition, upon request by either Party, the Parties shall meet to: (i) review traffic and usage data on End Office and Tandem Interconnection Trunk groups and (ii) determine whether the Parties should establish new Interconnection Trunk groups, augment existing Interconnection Trunk groups, or disconnect existing Interconnection Trunks.

  • Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.

  • Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.