Performance of the Services In addition to the Common Articles, it is specified that:
Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.
Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever.
(ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties.
(iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority.
(iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i).
(v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party.
(vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway.
(vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
Use of the Services 1.1 We will make the Oracle services listed in Your order (the “Services”) available to You pursuant to this Agreement and Your order. Except as otherwise stated in this Agreement or Your order, You have the non- exclusive, worldwide, limited right to use the Services during the period defined in Your order, unless earlier terminated in accordance with this Agreement or Your order (the “Services Period”), solely for Your internal business operations. You may allow Your Users (as defined below) to use the Services for this purpose, and You are responsible for their compliance with this Agreement and Your order.
1.2 The Service Specifications describe and govern the Services. During the Services Period, we may update the Services and Service Specifications (with the exception of the Data Processing Agreement as described below) to reflect changes in, among other things, laws, regulations, rules, technology, industry practices, patterns of system use, and availability of Third Party Content (as defined below). Oracle updates to the Services or Service Specifications will not materially reduce the level of performance, functionality, security or availability of the Services during the Services Period of Your order.
1.3 You may not, and may not cause or permit others to: (a) use the Services to harass any person; cause damage or injury to any person or property; publish any material that is false, defamatory, harassing or obscene; violate privacy rights; promote bigotry, racism, hatred or harm; send unsolicited bulk e-mail, junk mail, spam or chain letters; infringe property rights; or otherwise violate applicable laws, ordinances or regulations; (b) perform or disclose any benchmarking or availability testing of the Services; (c) perform or disclose any performance or vulnerability testing of the Services without Oracle’s prior written approval, or perform or disclose network discovery, port and service identification, vulnerability scanning, password cracking or remote access testing of the Services; or (d) use the Services to perform cyber currency or crypto currency mining ((a) through (d) collectively, the “Acceptable Use Policy”). In addition to other rights that we have in this Agreement and Your order, we have the right to take remedial action if the Acceptable Use Policy is violated, and such remedial action may include removing or disabling access to material that violates the policy.
Description of the Services 1.1 The scope of the service to be rendered is described more fully in the Annexures and Schedules referred to below: ❑ Annexure A – Scope / Specification ❑ Annexure C – Pricing Schedule The Deliverables, due for completion by and governed by this Schedule 1. In the event that the Service Provider fails to meet the delivery dates as agreed, the following penalties will be imposed:
Description of the service 10.1.1 Automatic transfer service implies a transfer by the bank of the funds from the client’s account without further consent of the client, on the basis of fixed amount determined by the client in its application form or of information provided by the client’s creditor to the bank on the client’s debt.
10.1.2 The parties agree that the payment order created (generated) by the bank for the purposes of automatic transfer services shall have the legal force equal to the document having been printed on the paper and executed by the person(s) authorized to manage of the account.
10.1.3 The bank shall carry out the automatic transfer services in accordance with requirements and conditions stipulated in this agreement, the application on registration for automatic transfer service and the sources disseminated by the bank.
10.1.4 For the purposes of obtaining automatic transfer services the client shall apply to the bank with the application as per paragraph 1.2 of this agreement.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Use of the Service 12.1 When using the Service you must comply with:
(a) our CRA, including clause 4 of the General Terms, and this clause 12; and
(b) any rules, including any acceptable use conditions, imposed by any third party whose content or services you access using the Service or whose Network on which your data transmits.
12.2 Any use of the Service at the Premises is your responsibility. The terms of our CRA apply to you and also to anyone else who uses the Service (regardless of whether you give them permission to do so or not).
12.3 You must ensure that any software you use in relation to the Service is properly licensed.
12.4 The use of a Local Area Network (LAN) for personal use is permitted, however the set-up and configuration of a LAN connected to the modem is not supported by customer service.
12.5 All IP addresses provided by us for your use remain our property. Most Services include a dynamic IP address. A new IP address is usually allocated whenever the computer and modem are rebooted. The IP address remains until the next time the computer and modem are switched off. Where provided, you may configure your computer or modem to connect using a static IP address.
12.6 We may at any time adjust aspects of the Service for security or Network management reasons, including, without limitation:
(a) deleting transitory data that has been stored on our servers for longer than 90 days;
(b) deleting stored email messages that are older than 90 days;
(c) rejecting any incoming email messages and attachments that exceed 30 Megabytes (including encapsulation);
(d) delivering access and content via proxy servers;
(e) limiting the number of addresses to whom an outgoing email can be sent;
(f) refusing to accept incoming email messages to mailboxes that have exceeded the email storage limit;
(g) managing the Network to prioritise certain types of Internet traffic over others; and
(h) blocking or filtering specific Internet ports.
12.7 You are responsible for providing any security or privacy measures for your computer networks and any data stored on those networks or accessed through the Service. We will not be liable to you in respect of any loss, damage, costs or expenses incurred by you in connection with your failure to provide that security.
12.8 You may request additional users on the Service in accordance with the Pricing Schedule.
12.9 You must take reasonable steps to ensure that others do not gain unauthorised access to the Service through your account. We recommend that you do not disclose your password to others and that you change your password regularly.
12.10 We may monitor use of the Service to investigate a breach (or suspected breach) of the Fair Use Policy or upon the request of an authorised authority.
12.11 Where you provide your own wireless computer connection device, you are responsible for any loss caused by an unauthorised interception of the Service.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Exclusivity of Services The Subadviser shall devote its best efforts and such time as it deems necessary to provide prompt and expert service to Client and the Fund. The services of Subadviser to be provided hereunder are not to be deemed exclusive and Subadviser shall be free to provide similar services for its own account and the accounts of other persons and to receive compensation for such services. Client acknowledges that Subadviser and its Affiliates and Subadviser's other clients may at any time, have, acquire, increase, decrease or dispose of positions in the same investments which are at the same time being held, acquired for or disposed of under this Agreement for the Fund. Subadviser shall have no obligation to acquire or dispose of a position in any investment pursuant to this Agreement simply because Subadviser, its directors, members, Affiliates or employees invest in such a position for its or their own accounts or for the account of another client.
