NMHS Governance, Safety and Quality Requirements 2.1 Participates in the maintenance of a safe work environment.
2.2 Participates in an annual performance development review.
2.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
2.4 Completes mandatory training (including safety and quality training) as relevant to role.
2.5 Performs duties in accordance with Government, WA Health, North Metropolitan Health Service and Departmental / Program specific policies and procedures.
2.6 Abides by the WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act.
SMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.
4.2 Participates in an annual performance development review.
4.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
4.4 Completes mandatory training (including safety and quality training) as relevant to role.
4.5 Performs duties in accordance with Government, WA Health, South Metropolitan Health Service and Departmental / Program specific policies and procedures.
4.6 Abides by the WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act.
EMHS Governance, Safety and Quality Requirements 4.1 Participates in the maintenance of a safe work environment.
4.2 Actively participates in the Peak Performance program.
4.3 Supports the delivery of safe patient care and the consumers’ experience including participation in continuous quality improvement activities in accordance with the requirements of the National Safety and Quality Health Service Standards and other recognised health standards.
4.4 Completes mandatory training (including safety and quality training) as relevant to role.
4.5 Performs duties in accordance with the EMHS Vision and Values, WA Health Code of Conduct, Occupational Safety and Health legislation, the Disability Services Act and the Equal Opportunity Act and Government, WA Health, EMHS and Departmental / Program specific policies and procedures.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Existence and Qualification; Power; Compliance With Laws Borrower is a corporation duly formed, validly existing and in good standing under the Laws of the State of California. Borrower is duly qualified or registered to transact business and is in good standing in the State of California, and each other jurisdiction in which the conduct of its business or the ownership or leasing of its Properties makes such qualification or registration necessary, except where the failure so to qualify or register and to be in good standing could not reasonably be expected to have a Material Adverse Effect. Borrower has all requisite power and authority to conduct its business, to own and lease its Properties and to execute and deliver each Loan Document to which it is a Party and to perform its Obligations. The chief executive offices of Borrower are located in San Dimas, California. All outstanding capital stock of Borrower is duly authorized, validly issued, fully paid and non-assessable, and no holder thereof has any enforceable right of rescission under any applicable state or federal securities or other Laws. Borrower is in compliance with all Laws and other legal requirements applicable to its business, has obtained all authorizations, consents, approvals, orders, licenses and permits from, and has accomplished all filings, registrations and qualifications with, or obtained exemptions from any of the foregoing from, any Governmental Agency that are necessary for the transaction of its business, except where the failure so to comply with Laws and other legal requirements applicable to its business, obtain authorizations, etc., file, register, qualify or obtain exemptions could not reasonably be expected to have a Material Adverse Effect.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Contractor Qualifications Contractor warrants that Contractor has the necessary licenses, experience and technical skills to provide services under this Contract.
Certification Requirements The hospice program certifies and attaches hereto documentation that:
(a) it is Medicare approved and meets all Medicare conditions of participation (42 CFR 418); and
(b) is licensed pursuant to any applicable state or local law.
Existence, Qualification and Power; Compliance with Laws Each Loan Party (a) is duly organized or formed, validly existing and in good standing under the Laws of the jurisdiction of its incorporation or organization, (b) has all requisite power and authority and all requisite governmental licenses, authorizations, consents and approvals to (i) own its assets and carry on its business and (ii) execute, deliver and perform its obligations under the Loan Documents to which it is a party, (c) is duly qualified and is licensed and in good standing under the Laws of each jurisdiction where its ownership, lease or operation of properties or the conduct of its business requires such qualification or license, and (d) is in compliance with all Laws; except in each case referred to in clause (b)(i), (c) or (d), to the extent that failure to do so could not reasonably be expected to have a Material Adverse Effect.
