Provisions of General Application (a) All accounting terms not specifically defined herein shall be construed in accordance with GAAP. (b) The terms defined in this Article include the plural as well as the singular. (c) The words "herein," "hereof" and "hereunder" and other words of similar import refer to this Agreement as a whole. All references to Articles and Sections shall be deemed to refer to Articles and Sections of this Agreement.
Other Provisions of General Application Section 7.1 Notices to the Rights Agent, Parent and the Stockholders’ Representative. Any notice, request, instruction or other document to be given hereunder by any party to the others shall be in writing and delivered personally or sent by registered or certified mail, postage prepaid, by electronic mail (except with respect to the Rights Agent), by facsimile transmission only with respect to the Rights Agent or overnight courier, provided that with respect to notices deliverable to the Stockholders’ Representative, such notices shall be delivered solely via electronic mail or facsimile: If to Parent or the Company: Eros International Plc First Names House Victoria Road Xxxxxxx Isle of Man IM2 4DF British Isles Attention: Xxxx Xxxxxxx, Chief Corporate and Strategy Officer Email: xxxx.xxxxxxx@xxxxxxxx.xxx with a copy (which shall not constitute notice) to: Xxxxxx, Xxxx & Xxxxxxxx LLP 000 Xxxxx Xxxxx Xxxxxx Xxx Xxxxxxx, Xxxxxxxxxx 00000-0000 Attention: Xxxxx Xxxxxx Xxxxx Xxxxxx Email: xxxxxxx@xxxxxxxxxx.xxx xxxxxxx@xxxxxxxxxx.xxx If to the Rights Agent: Computershare Trust Company, N.A., Computershare Inc. 000 Xxxxxx Xxxxxx Canton, MA 02021 Attention: Client Services Facsimile: (000) 000-0000 If to the Stockholders’ Representative: Fortis Advisors LLC Attention: Notices Department (Project World Cup) Email: xxxxxxx@xxxxxxxxx.xxx Facsimile: (000) 000-0000 with a copy (which shall not constitute notice) to: Xxxxxxxx & Xxxxx LLP 000 Xxxxx Xxxxxx Xxxxxx, Xxxxx 0000 Xxx Xxxxxxx, Xxxxxxxxxx 00000 Attention: Xxxx X. Xxxxxx, P.C. Email: xxxx.xxxxxx@xxxxxxxx.xxx or to such other persons or addresses as may be designated in writing by the party to receive such notice as provided above. Any notice, request, instruction or other document given as provided above shall be deemed given to the receiving party upon actual receipt, if delivered personally; three (3) business days after deposit in the mail, if sent by registered or certified mail; upon confirmation of successful transmission if sent by electronic mail; or on the next business day after deposit with an overnight courier, if sent by an overnight courier.
Definitions of General Application For purposes of this Agreement, unless otherwise specified: Agreement means the Free Trade Agreement between the Government of the People's Republic of China and the Government of the Republic of Peru; Commission means the Free Trade Commission established under Article 170 (Free Trade Commission) of Chapter 14 (Administration of the Agreement);
Procedures for Actions and Consents of Partners The actions requiring Consent of any Partner or Partners pursuant to this Agreement, including Section 7.3 hereof, or otherwise pursuant to applicable law, are subject to the procedures set forth in this Article 14.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Conditions of Eft Services (a.) Ownership of Card(s). Any Card we supply to you is our property and must be returned to us, or to any person whom we authorize to act as our agent, or to any person who is authorized to honor the Card, immediately according to instructions. The Card may be reclaimed at any time at our sole discretion without demand or notice. You cannot transfer your Card to another person.
Purpose; Incorporation by Reference of Auction Procedures and Settlement Procedures (a) The Statement for each series of MuniPreferred will provide that the Applicable Rate for such series for each Subsequent Rate Period thereof shall, except under certain conditions, be the rate per annum that a bank or trust company appointed by the Fund advises results from implementation of the Auction Procedures for such series. The Board of Directors or Board of Trustees, as the case may be, of the Fund has adopted a resolution appointing the Auction Agent as auction agent for purposes of the Auction Procedures for each series of MuniPreferred. The Auction Agent accepts such appointment and agrees to follow the procedures set forth in this Section 2 and the Auction Procedures for the purpose of determining the Applicable Rate for each series of MuniPreferred for each Subsequent Rate Period thereof for which the Applicable Rate is to be determined by an Auction. Each periodic implementation of such procedures is hereinafter referred to as an "Auction." (b) All of the provisions contained in the Auction Procedures and the Settlement Procedures are incorporated herein by reference in their entirety and shall be deemed to be a part hereof to the same extent as if such provisions were fully set forth herein.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Definitions and Other Provisions of General Application SECTION 101.