District Use of Design Documents Sample Clauses

District Use of Design Documents. Upon the termination of this Agreement, a Project Assignment Amendment or the abandonment of all or any portion of an Assigned Project, the District may use any portion of the Design Documents (whether completed or in progress) for any purpose, in the sole and exclusive discretion of the District without additional compensation to the A/E. Whether the Assigned Project is completed or if completion of the Design documents or construction of an Assigned Project is not by the A/E under this Agreement and the District re-uses or modifies Design Documents completed by the A/E or prepared by the A/E prior to the termination of this Agreement, termination of a project
AutoNDA by SimpleDocs
District Use of Design Documents. Upon the termination of this Agreement, a Project Assignment Amendment or the abandonment of all or any portion of an Assigned Project, the District may use any portion of the Design Documents (whether completed or in progress) for any purpose, in the sole and exclusive discretion of the District without additional compensation to the A/E. Whether the Assigned Project is completed or if completion of the Design documents or construction of an Assigned Project is not by the A/E under this Agreement and the District re-uses or modifies Design Documents completed by the A/E or prepared by the A/E prior to the termination of this Agreement, termination of a project Assignment Amendment or the abandonment of an Assigned Project, the District shall indemnify, defend and hold harmless the A/E from claims, liabilities, suits, demands, losses, costs and expenses, including reasonable attorneys fees and legal costs arising out of damage or loss to property or persons, including death, arising out of the District’s re-use or modification of the A/E’s Design Documents. The foregoing notwithstanding, the District shall not be liable for the defense, indemnity or hold harmless of the A/E if the A/E is determined by an arbitrator (or arbitration panel) or a court of competent jurisdiction to be liable for such damages or losses.‌
District Use of Design Documents. Upon the termination of this Agreement, a Project Assignment Amendment or the abandonment of all or any portion of an Assigned Project, the District may use any portion of the Design Documents (whether completed or in progress) for any purpose, in the sole and exclusive discretion of the District without additional compensation to the Architect. Whether the Assigned Project is completed or if completion of the Design documents or construction of an Assigned Project is not by the Architect under this Agreement and the District re-uses or modifies Design Documents completed by the Architect or prepared by the Architect prior to the termination of this Agreement, termination of a project Assignment Amendment or the abandonment of an Assigned Project, the District shall indemnify, defend and hold harmless the Architect from claims, liabilities, suits, demands, losses, costs and expenses, including reasonable attorneys fees and legal costs arising out of damage or loss to property or persons, including death, arising out of the District’s re- use or modification of the Architect’s Design Documents. The foregoing notwithstanding, the District shall not be liable for the defense, indemnity or hold harmless of the Architect if the Architect is determined by an arbitrator (or arbitration panel) or a court of competent jurisdiction to be liable for such damages or losses.

Related to District Use of Design Documents

  • Schematic Design Documents In accordance with the approved Preliminary Design and Construction Schedule and based upon approval of and comments made by the Owner regarding the Concept Design Studies, the Design Professional shall prepare and submit to the Owner Schematic Design Documents, including drawings and outline specifications. These documents shall represent a further development of the approved design concept, providing additional detail and specificity regarding the intended design solution. Typically, all such documents shall be drawn to scale, indicating materials and assemblies, as appropriate, to convey the design intent and to illustrate the Project’s basic elements, scale and relationship to the Site. All major pieces of furniture and equipment to be fixed or supplied by the CM/GC shall be illustrated to scale. (See ASTM Standard Practice E 1804-02, August 2007, Sections 6.3, 8.2 and 8.3 for guidance on information which is generally developed in Schematic Design.)

  • Design Documents Prepare and submit the following documents to the DAS - Records Management Office with a copy of the transmittal letter submitted to the respective Project Manager: 1. City/State Approved Drawings (1) Original set 2. Bid Set Drawings (1) Set BOND PAPER (marked as “ORIGINAL”) (1) Set electronic file (DWG & PDF) 3. Project Manual (1) Set hard copy & Detail Manual (1) Set electronic file

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • Construction Document Phase 1.4.1 Based on the approved Design Development Documents, Guaranteed Maximum Price, coordinated models and any further adjustments in the scope or quality of the Project or in the Amount Available for the Construction Contract authorized by the Owner, the Architect/Engineer shall prepare, for approval by the Owner and review by the Construction Manager, Construction Documents consisting of Drawings, Schedules and Specifications derived from the model(s) in accordance with Owner’s written requirements setting forth in detail the requirements for construction of the Project, including, without limitation, the BIM Execution Plan and “Facility Design Guidelines”. The Plans, Drawings and Specifications for the entire Project shall be so prepared that same will call for the construction of the building and related facilities, together with its built-in permanent fixtures and equipment which will cost not more than the Guaranteed Maximum Price accepted by Owner, or the Amount Available for the Construction Contract established by Owner if no Guaranteed Maximum Price proposal has been accepted by Owner. The Architect/Engineer will be responsible for managing the design to stay within such Guaranteed Maximum Price proposal or Amount Available for the Construction Contract. The Architect/Engineer shall review the Construction Documents as they are being prepared at intervals appropriate to the progress of the Project with the Owner and Construction Manager at the Project site or other location specified by Owner in the State of Texas. The Architect/Engineer shall utilize the model(s) to support the review process during Construction Documents. The Architect/Engineer shall provide the Construction Manager with a compact disc containing documents and data files derived from the model to assist the Construction Manager in fulfilling its responsibilities to the Owner. 1.4.2 As a part of Construction Documents Phase, Architect/Engineer shall accomplish model coordination, aggregation and “clash detection” to remove conflicts in design between systems, structures and components. Architect/Engineer shall demonstrate and provide written assurance to Owner that all conflicts/collisions between models have been resolved. 1.4.3 The Architect/Engineer shall consult with the Owner and Construction Manager on matters such as construction phasing and scheduling, bid or proposal alternates, liquidated damages, the construction contract time period, and other construction issues appropriate for the Project. The Architect/Engineer shall assist the Owner and Construction Manager in the preparation of the necessary bidding information, bidding forms, RFP information, and RFP forms, and the Conditions of the Contract. 1.4.4 The Architect/Engineer shall assist the Owner in connection with the Owner’s responsibility and procedures for obtaining approval of all building and accessibility authorities having jurisdiction over the Project. 1.4.5 The Architect/Engineer shall provide coordination and inclusion of sequence of operations for all operable systems in the facility as defined by Owner during Design Development. 1.4.6 The Architect/Engineer shall review the Estimated Construction Cost prepared by the Construction Manager, and shall provide written comments. 1.4.7 The Architect/Engineer shall participate in a final review of the Construction Documents and model(s) with the Owner and Construction Manager at the Project location or other location specified by Owner in the State of Texas. Prior to the Owner’s approval of the Construction Documents, the Architect/Engineer shall incorporate such changes as are necessary to satisfy the Owner’s review comments. 1.4.8 Before proceeding into the Bidding and Proposal Phase, the Architect/Engineer shall obtain Owner’s written acceptance of the Construction Documents and approval of the Final Amount Available for the Construction Contract as approved by the Board of Regents.

  • Schedules and Exhibits Incorporated The Schedules and Exhibits annexed hereto are hereby incorporated herein as a part of this Agreement with the same effect as if set forth in the body hereof.

  • Note to Design Professional Please insert the number of additional Days allowed and the new Material Completion and Occupancy Date, or, if no additional time is allowed, insert “0” for the Days and “No Change” for the date.

  • Incorporation of Schedules and Exhibits The schedules, attachments and exhibits referenced in and attached to this Agreement shall be deemed an integral part hereof to the same extent as if written in whole herein. In the event that any inconsistency or conflict exists between the provisions of this Agreement and any schedules, attachments or exhibits attached hereto, the provisions of this Agreement shall supersede the provisions of any such schedules, attachments or exhibits.

  • MSAA Indicator Technical Specification Document This Agreement shall be interpreted with reference to the MSAA Indicator Technical Specifications document.

  • Exhibits and Schedules Incorporated The Exhibits and Schedules annexed hereto are hereby incorporated herein as a part of this Agreement with the same effect as if set forth in the body hereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!