OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
STUDENT’S RIGHT TO CANCEL You have the right to cancel this agreement and obtain a refund of charges paid through the attendance at the first class session, or the seventh day after enrollment, whichever is later.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Fund's Right to Proceed Notwithstanding anything to the contrary contained herein, each Fund shall have, at its election upon reasonable notice to the Custodian, the right to enforce, to the extent permitted by any applicable agreement and applicable law, the Custodian's rights against any Subcustodian, Securities System, Eligible Securities Depository or other Person for loss, damage or expense caused such Fund by such Subcustodian, Securities System, Eligible Securities Depository or other Person, and shall be entitled to enforce the rights of the Custodian with respect to any claim against such Subcustodian, Securities System, Eligible Securities Depository or other Person, which the Custodian may have as a consequence of any such loss, damage or expense, if and to the extent that such Fund has not been made whole for any such loss or damage. If the Custodian makes such Fund whole for any such loss or damage, the Custodian shall retain the ability to enforce its rights directly against such Subcustodian, Securities System, Eligible Securities Depository or other Person. Upon such Fund's election to enforce any rights of the Custodian under this Section 5.05, such Fund shall reasonably prosecute all actions and proceedings directly relating to the rights of the Custodian in respect of the loss, damage or expense incurred by such Fund; provided that, so long as such Fund has acknowledged in writing its obligation to indemnify the Custodian under Section 5.03 hereof with respect to such claim, such Fund shall retain the right to settle, compromise and/or terminate any action or proceeding in respect of the loss, damage or expense incurred by such Fund without the Custodian's consent and provided further, that if such Fund has not made an acknowledgment of its obligation to indemnify, such Fund shall not settle, compromise or terminate any such action or proceeding without the written consent of the Custodian, which consent shall not be unreasonably withheld or delayed. The Custodian agrees to cooperate with each Fund and take all actions reasonably requested by such Fund in connection with such Fund's enforcement of any rights of the Custodian. Each Fund agrees to reimburse the Custodian for all reasonable out-of-pocket expenses incurred by the Custodian on behalf of such Fund in connection with the fulfillment of its obligations under this Section 5.05; provided, however, that such reimbursement shall not apply to expenses occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian.
Ability to Carry Out Obligations Company has the right, power, and authority to enter into and perform its obligations under this Agreement. The execution and delivery of this Agreement by Company and the performance by Company of its obligations hereunder will not cause, constitute, or conflict with or result in (a) any breach of violation or any of the provisions of or constitute a default under any license, indenture, mortgage, charter, instrument, articles of incorporation, bylaw, or other agreement or instrument to which Company is a party, or by which either of them may be bound, nor will any consents or authorizations of any party other than those hereto be required; (b) an event that would cause Company to be liable to any party; or (c) an event that would result in the creation or imposition of any lien, charge, encumbrance on any asset of Company.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Application to Court If (i) a claim for indemnification or advancement of Expenses is denied, in whole or in part, (ii) no disposition of such claim is made by the Company within ninety (90) days after the request therefore, (iii) the advancement of Expenses is not timely made pursuant to Section 6 of this Agreement or (iv) payment of indemnification is not made pursuant to Section 5 of this Agreement, the Indemnitee shall have the right to apply to the Delaware Court of Chancery, the court in which the Proceeding is or was pending, or any other court of competent jurisdiction, for the purpose of enforcing the Indemnitee’s right to indemnification (including the advancement of Expenses) pursuant to this Agreement.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Right to Petition Court In the event that Indemnitee makes a request for payment of Indemnifiable Amounts under Sections 3 and 5 above or a request for an advancement of Indemnifiable Expenses under Sections 8 and 9 above and the Company fails to make such payment or advancement in a timely manner pursuant to the terms of this Agreement, Indemnitee may petition the Court of Chancery to enforce the Company’s obligations under this Agreement.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
