DRILLING AND COMPLETION OF XXXXX Sample Clauses

DRILLING AND COMPLETION OF XXXXX. (Applicable separately to each well) All operations conducted by Farmee, it successors and assigns shall be at Farmee's sole cost, risk and expense. Farmee agrees to indemnify, defend and hold Amoco harmless from and against all claims, demands, causes of action and judgments of any nature (and all costs and fees associated with same) arising in favor of any party (including Farmee, Farmee's employees, agents, servants, contractors or invitees or Amoco's employees and any other party whomsoever) for personal injury, death, property damage, damage to natural resources, or for any other reason whatsoever, growing out of, incident to, or arising, either directly or indirectly, from Farmee's, its successors and assigns, operations on or with respect to the Exploration Area. Farmee further agrees to pay Amoco for any damages to Amoco's property which is caused by Farmee, Farmee's employees, agents, servants, contractors or invitees or Farmee's successors and assigns. Prior to building the location for any well drilled hereunder, Farmee shall furnish Amoco with a detailed plat showing the location of the well. Farmee shall notify Amoco immediately when the location for each well to be drilled hereunder is staked, when the material for the drilling thereof is moved to the location and when actual drilling is commenced. Farmee shall provide to Amoco one (1) copy of the staking plat, along with the Kansas Corporation Commission "Permit To Drill" at no cost to Amoco. After actual drilling has been commenced and continuing until Farmee has completed as a well capable of producing oil and/or gas in commercial quantities, is taken over by Amoco as provided for in Article Eleven (11) below, or is plugged and abandoned as a dry hole, Farmee shall furnish to Amoco daily reports as to the progress as well as any and all other information requested by Amoco as set forth in the Geological Requirements included herein as Exhibit "C". Once a well has reached contract Depth and Farmee determines that the well drilled is incapable of producing oil or gas in commercial quantities and that said well should be plugged and abandoned, and Amoco has declined to takeover the well as provided for in article Eleven (11) below, Farmee shall proceed at Farmee's sole cost, risk and expense to plug and abandon said well in accordance with all applicable state and local laws and regulations. Farmee shall additionally level the ground around the location and clean the premises so as to comply ...
Sample 1Sample 2
AutoNDA by SimpleDocs
DRILLING AND COMPLETION OF XXXXX. Solaris agrees to notify NPG immediately of all material events occurring on the Leases, including, without limitation, when the location for each Well is staked, when the material for the drilling thereof is moved to the location and when actual drilling is commenced.
Sample 1

Related to DRILLING AND COMPLETION OF XXXXX

  • Commencement and Completion of Work The professional services to be performed pursuant to this Agreement shall commence within five (5) days from the Effective Date of this Agreement. Failure to commence work in a timely manner and/or diligently pursue work to completion may be grounds for termination of this Agreement.

  • COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.

  • Commencement and Completion The Work shall commence on _______________, 20__ and shall be complete in accordance with this Agreement without delay on ______________, 20__. The term “day”, used throughout this Agreement, refers to calendar days. Contractor shall not be entitled to any additional compensation for any Permitted Delays. If this Agreement is not signed and returned to the Owner before any work commences, this Agreement will be considered as accepted as presented to the Contractor.

  • PROGRESS AND COMPLETION 8.2.1 All time limits stated in the Contract Documents are material terms and time is the essence of the Contract. A failure by Contractor to do what is required by the time specified in the Contract Documents is a breach of the contract. 8.2.2 The Contractor shall begin the Work on the date of commencement as defined in 8.2.3 If in the sole opinion of the State, the Contractor fails to commence work on the project or to complete the work of said project within the time specified above, or to prosecute the work in such a manner that it appears that the completion date can be assured, the State shall have the right to notify the Contractor by Certified Mail that the terms of the Contract have been violated, and that effective immediately the Contract is terminated and the State has the right to and in fact is taking over and attending to completion of the project without prejudice to the State's remedies for any losses sustained

  • DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK

  • Schedule and Completion The Pre-commencement Phase Services to be performed under this Contract shall commence upon the Effective Date of the Contract and be completed within 60 days thereafter. Activities on the Site shall commence on the date specified in the Proceed Order and shall be materially complete in accordance with established Milestones, and not later than the Material Completion and Occupancy Date.

  • COMPLETION OF AGREEMENT This document comprises the entire agreement between the District and the Association in the matters lawfully within the scope of negotiation. Neither party shall have any obligation to meet and negotiate during the term of this agreement.

  • Synchronization, Commissioning and Commercial Operation 4.1.1 The Power Producer shall give at least fifteen (15) days written notice to the SLDC / ALDC / DISCOM as the case may be, of the date on which it intends to synchronize the Power Project to the Grid System. 4.1.2 Subject to Article 4.1.1, the Power Project may be synchronized by the Power Producer to the Grid System when it meets all the connection conditions prescribed in the Grid Code and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 4.1.3 The synchronization equipment and all necessary arrangements / equipment including Remote Terminal Unit (RTU) for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the Power Producer at its generation facility of the Power Project at its own cost. The Power Producer shall synchronize its system with the Grid System only after the approval of GETCO / SLDC / ALDC and GEDA. 4.1.4 The Power Producer shall immediately after each synchronization / tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. 4.1.5 The Power Producer shall commission the Project within SCOD. 4.1.6 The Power Producer shall be required to obtain Developer and/ or Transfer Permission, Key Plan drawing etc, if required, from GEDA. In cases of conversion of land from Agricultural to Non-Agriculture, the commissioning shall be taken up by GEDA only upon submission of N.A. permission by the Power Producer. 4.1.7 The Power Producer shall be required to follow the Forecasting and Scheduling procedures as per the Regulations issued by Hon’ble GERC from time to time. It is to clarify that in terms of GERC (Forecasting, Scheduling, Deviation Settlement and Related Matters of Solar and Wind Generation Sources) Regulations, 2019 the procedures for Forecasting, Scheduling & Deviation Settlment are applicable to all solar generators having combined installed capacity above 1 MW connected to the State Grid / Substation including those connected via pooling stations.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Completion of Negotiations This Agreement represents complete collective bargaining and full agreement by the District and the Federation with respect to wages, hours of employment, and all other terms and conditions of employment which shall prevail during the term or terms hereof. This Agreement expresses the entire understanding between the parties and supersedes all previous agreements between them, written or oral. Any matter or subject not herein covered has been satisfactorily adjusted, compromised, or waived by the parties for the life of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!