TERM; POSSESSION The Term of this Lease shall commence on the Commencement Date and shall end on the Expiration Date, unless extended or sooner terminated in accordance with this Lease. If Landlord is delayed in delivering possession of all or any portion of the Premises to Tenant as of the Commencement Date, Tenant will take possession on the date Landlord delivers possession, which date will then become the Commencement Date (and the Expiration Date will be extended so that the length of the Term remains unaffected by such delay). Subject to this Section 4, Landlord shall not be liable for any loss or damage to Tenant resulting from any delay in delivering possession due to the holdover of any existing tenant or other circumstances outside of Landlord’s reasonable control. In the event that the Tenant Improvements are not Substantially Completed within one hundred (100) days following the date that Landlord receives a building permit to commence the Tenant Improvements in the Premises (the “Delivery Date”), subject to Tenant Delay or force majeure (in the event of either, the Delivery Date shall be extended by one (1) day for each one (1) day of Tenant Delay or force majeure), Landlord shall credit Tenant against Minimum Annual Rent due under this Lease an amount equal to the holdover portion of Tenant’s existing rental obligations under Tenant’s existing Lease actually incurred by Tenant following the Delivery Date, which Tenant represents to Landlord is equal to $17,031.13 per month. Notwithstanding anything in this Lease to the contrary, if the Commencement Date has not occurred on or before one hundred ninety (190) days following the date that Landlord receives a building permit for the Tenant Improvements, for any reason other than Tenant Delay or force majeure, then Tenant shall have the right to terminate this Lease by written notice to Landlord, as Tenant’s sole and exclusive remedy with respect to such delay, except as provided above, subject to Tenant giving Landlord thirty (30) days’ advance written notice of its intention to terminate this Lease if Substantial Completion shall not occur within such thirty (30) day period, in which event all amounts prepaid or deposited by Tenant hereunder shall be promptly returned to Tenant.
Project or Building Name and Signage Landlord shall have the right at any time to change the name of the Project or Building and to install, affix and maintain any and all signs on the exterior and on the interior of the Project or Building as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the name of the Project or Building or use pictures or illustrations of the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises, without the prior written consent of Landlord.
Quiet Possession Upon Tenant paying the rent reserved hereunder and observing and performing all of the covenants, conditions and provisions on Tenant's part to be observed and performed hereunder, Tenant shall have quiet possession of the Premises for the entire term hereof, subject to all the provisions of this Lease.
Use and Possession of Certain Premises Upon the occurrence and during the continuance of an Event of Default, the Administrative Agent shall be entitled to occupy and use any premises owned or leased by the Grantors where any of the Collateral or any records relating to the Collateral are located until the Secured Obligations are paid or the Collateral is removed therefrom, whichever first occurs, without any obligation to pay any Grantor for such use and occupancy.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Term and Possession (a) Subject to and upon the terms and conditions set forth herein, the Term of this Lease shall be for the period specified in the Basic Lease Information. The Term shall commence on the earlier of (i) the date that the Premises is delivered to Tenant free and clear of any third-party occupancy and (ii) the date that Tenant first commences normal business operation from the Premises (the “Commencement Date”). In the event of the inability of Landlord to deliver possession of the Premises for any reason whatsoever, including, without limitation, the vacating of the Premises by the prior tenant of the Premises, neither Landlord nor its agents shall be liable for any damage caused thereby, nor shall this Lease thereby become void or voidable, however, in such event Tenant shall not be liable for any rent until the actual occurrence of the Commencement Date. Notwithstanding the foregoing to the contrary, if, for any reason, Landlord has not delivered possession of the Premises to Tenant as described in clause (i) above as of January 1, 2020, Tenant, as Tenant’s sole remedy, will have the right to terminate this Lease by written notice delivered to Landlord at any time prior to Landlord’s delivery of possession of the Premises to Tenant; provided, however, that such January 1, 2020 date shall be extended so long as Landlord is using its good faith and diligent efforts to deliver possession of the Premises to Tenant (by unlawful detainer or otherwise). Within thirty (30) days after the Commencement Date, Landlord and Tenant shall execute an amendment to this Lease (“First Amendment to Lease and Acknowledgment”) setting forth the Commencement Date and the expiration date of the term of the Lease, which shall be in the form attached hereto as Exhibit B.
(b) Tenant shall have the one-time option to terminate and cancel the Lease effective on the last day of the eighty-fifth (85th) month after the Commencement Date (the “Termination Date”), which right is contingent upon Tenant paying to Landlord the “Termination Consideration” (as defined below) concurrent with Tenant’s delivery of the Termination Notice (as defined below). To exercise such termination option, Tenant must deliver to Landlord on or before January 1, 2025, irrevocable written notice of Tenant’s exercise of such option (the “Termination Notice”) and the amount of the Termination Consideration. As used herein, the “Termination Consideration” shall mean the amount equal to Two Million and No/100ths Dollars ($2,000,000.00). Failure by Tenant to timely pay the Termination Consideration shall terminate Tenant’s option to terminate this Lease. If Tenant properly and timely exercises the termination option in this Section 4(b), this Lease shall expire at midnight on the Termination Date and Tenant shall be required to surrender the Premises to Landlord on or prior to such Termination Date in accordance with the applicable provisions of this Lease. The option to terminate set forth in this Section 4(b) is personal to the original Tenant executing this Lease and may not be assigned, voluntarily or involuntarily, separate from or as part of this Lease. At Landlord’s option, all rights of Tenant under this Section 4(b) shall terminate and be of no force or effect if any of the following individual events occur or any combination thereof occur: (1) Tenant has been in default beyond any notice and cure period on more than one (1) occasion during any consecutive twelve (12) month period during the initial Term of the Lease, or is in default of any provision of this Lease on the date Landlord receives the Termination Notice; and/or (2) Tenant has assigned its rights and obligations under all or part of this Lease; and/or (3) Tenant has failed to exercise the early termination option set forth in this Section 4(b) in a timely manner and in strict accordance with the provisions of this Section 4(b).
Procedure for taking possession The Promoter, upon obtaining the occupancy certificate* from the competent authority shall offer in writing the possession of the [Apartment/Plot], to the Allottee in terms of this Agreement to be taken within two months from the date of issue of occupancy certificate. [Provided that, in the absence of local law, the conveyance deed in favour of the allottee shall be carried out by the promoter within 3 months from the date of issue of occupancy certificate]. The Promoter agrees and undertakes to indemnify the Allottee in case of failure of fulfillment of any of the provisions, formalities, documentation on part of the Promoter. The Allottee, after taking possession, agree(s) to pay the maintenance charges as determined by the Promoter/association of allottees, as the case may be after the issuance of the completion certificate for the project. The promoter shall hand over the occupancy certificate of the apartment/ plot, as the case may be, to the allottee at the time of conveyance of the same.
Documents, Records and Funds in Possession of the Master Servicer to be Held for the Trustee. The Master Servicer shall account fully to the Trustee for any funds it receives or otherwise collects as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, the Collection Account, Distribution Account, or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment, or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
POSSESSION OF THE APARTMENT PLOT
8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions.
8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex.
8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
NO VACANT POSSESSION 14.1 The Purchaser shall upon full payment of the Balance Purchase Price together with all interest on late payment (if any) be entitled at his own costs and expenses to take possessions of the Property.
14.2 The Bank shall not be under any obligation whatsoever to deliver vacant possession of the Property or to forward to the Purchaser or any party any keys to the Property.
14.3 The Property is sold subject to all existing easements, leases, tenancies, occupiers, charges, caveats, previous Sale and Purchase, previous assignment, covenants, liabilities subsisting thereon or thereover and the Purchaser shall be deemed to have full knowledge of the state and condition of the Property.
