APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Ability to Abandon CVR A Holder may at any time, at such Holder’s option, abandon all of such Holder’s remaining rights in a CVR by transferring such CVR to Parent without consideration therefor. Nothing in this Agreement is intended to prohibit Parent from offering to acquire CVRs for consideration in its sole discretion.
Ability to Service The Servicer is an approved seller/servicer of conventional residential mortgage loans for Xxxxxx Xxx or Xxxxxxx Mac, with the facilities, procedures and experienced personnel necessary for the sound servicing of mortgage loans of the same type as the Mortgage Loans. The Servicer is in good standing to service mortgage loans for either Xxxxxx Mae or Xxxxxxx Mac. The Servicer is a member in good standing of the MERS system;
Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions:
(i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim.
(ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed.
(iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.
DEVELOPMENT OR ASSISTANCE IN DEVELOPMENT OF SPECIFICATIONS REQUIREMENTS/ STATEMENTS OF WORK
Provision of Services by Third Parties The Administrator shall, to the extent it determines that it would be advisable in connection with or incidental to the activities contemplated hereby, arrange for and coordinate the services of other professionals, experts and consultants to provide any or all of the Services, in which case, the costs and expenses of such third parties for providing such services shall be borne by the Administrator other than as set forth in Section 3; it being understood that the Administrator shall not charge to the Issuer any fees in addition thereto with respect to such outsourced Painting-Level Services that are described in Section 1(a)(i) and Entity-Level Services described in Section 1(a)(ii), but the Administrator shall be entitled to reimbursement for third party costs incurred in connection with Non-Routine Services described in Section 1(a)(iii) as set forth in Section 3(b). Reimbursement for Non-Routine Services shall be reimbursed by the Issuer out of the proceeds from a sale of the Painting. In addition, Masterworks may determine to sell the Painting without engaging a third-party intermediary, in which event, the Administrator would charge the buyer of the Painting a reasonable fee not to exceed the lowest published buyer’s premium charged by Sotheby’s, Christie’s or Pxxxxxxx in effect at such time.
Technical Feasibility of String While ICANN has encouraged and will continue to encourage universal acceptance of all top-‐level domain strings across the Internet, certain top-‐level domain strings may encounter difficulty in acceptance by ISPs and webhosters and/or validation by web applications. Registry Operator shall be responsible for ensuring to its satisfaction the technical feasibility of the TLD string prior to entering into this Agreement.
Evaluation of Students Acknowledging the District’s adopted grading system, the teacher shall maintain the right and responsibility to determine grades and other evaluation of a student. No grade or evaluation shall be changed except by the teacher with the approval of the building administrator.
Warranty of Ability to Perform Upon the effective date of the Term Contract, and each year on the anniversary date of the Term Contract, the Contractor shall submit to the Department a completed PUR 7801, Vendor Certification Form. The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Term Contract obligations. Additionally, the Contractor shall promptly notify the Department in writing if its ability to perform is compromised in any manner during the term of the Term Contract (including potential inability to renew the Term Contract due to section 287.138 or 908.111, F.S.) or if it or its suppliers, subcontractors, or consultants under the Term Contract are placed on the Suspended Vendor, Convicted Vendor, Discriminatory Vendor, Forced Labor Vendor, or Antitrust Violator Vendor Lists. The Contractor shall use commercially reasonable efforts to avoid or minimize any delays in performance and shall inform the Department of the steps the Contractor is taking or will take to do so, and the projected actual completion (or delivery) time. If the Contractor believes a delay in performance by the Department has caused or will cause the Contractor to be unable to perform its obligations on time, the Contractor shall promptly so notify the Department and use commercially reasonable efforts to perform its obligations on time notwithstanding the Department’s delay.
