Exceptions to Waiver. The exclusion of consequential damages set forth in Section 21.6.1 shall not exclude or affect: (a) Any liability for any type of damage or loss to the extent it is covered by the proceeds of insurance (i) required to be carried pursuant to Section 16, or (ii) actually carried by Developer under policies solely with respect to the Project and the Work, regardless of whether required to be carried pursuant to Section 16; (b) Any liability, obligation, loss, damage, cost or expense arising out of illegal activities, fraud, criminal conduct, gross negligence or intentional misconduct on the part of TxDOT or any Developer-Related Entity; (c) Developer’s liability respecting indemnities set forth elsewhere in this Agreement or the other Contract Documents; (d) Developer’s obligation to pay any liquidated damages expressly provided for in the Contract Documents; (e) Liability for other damages expressly provided for in the Contract Documents; and (f) Any liability, obligation, loss, damage, cost or expense arising out of any Facility Agreement or any act or omission of any Developer-Related Entity or TxDOT regarding any Facility occurring after the Close of Finance for such Facility, as to which the provisions of the applicable Facility Agreements shall exclusively govern Developer-Related Entities’ and TxDOT’s respective liabilities for consequential damages and any limits thereon or waivers thereof.

Exceptions to Waiver. (1) The waiver under this T] 67 shall not apply with respect to any defense, claim, or cause of action that a Respondent may have against any person otherwise covered by such waiver if such person asserts a claim or cause of action relating to the. Site against such Respondent. (2) The waiver under 1 67.a.l (De Micromis Waiver) shall not apply to any claim or cause of action against any person otherwise covered by such waiver, if EPA determines that; (i) that the materials containing hazardous substances contributed to the Site by such person have contributed significantly, or could contribute significantly, either individually or in the aggregate, to the cost of response action or natural resource restoration at the Site; or (ii) such person has failed to comply with any EPA requests for information or administrative subpoenas issued pursuant to Section 104(e) or 122(e) of CERCLA, 42 U.S.C. §§ 9604(e) or 9622(e), or Section 3007 of RCRA, 42 U.S.C. § 6927, or has impeded or is impeding, through action or inaction, the performance ofa response action or natural resource restoration with respect to the Site; or if (iii) such person has . been convicted of a criminal violation for the conduct to which this waiver would apply and that conviction has not been vitiated on appeal or otherwise.

Exceptions to Waiver. The foregoing limitation will not, however, in any manner: (a) limit Owner’s liability for any type of damage arising out of Owner’s obligation to indemnify, protect, defend and hold each Indemnified Parties harmless under this Agreement; (b) limit any losses arising out of fraud, gross negligence, criminal conduct, intentional misconduct, recklessness or bad faith on the part of the relevant Party; or (c) limit the amounts expressly provided to be payable by either Party pursuant to this Agreement.

Exceptions to Waiver. The foregoing limitation will not, however, in any manner: (a) limit any losses of the Developer arising under its Subcontracts or other agreements as originally executed (or as amended in accordance with the terms of this Agreement); (b) prejudice the City’s right to recover any or all of liquidated damages under this Agreement; (c) limit the Developer’s liability for any type of damage arising out of the Developer’s obligation to indemnify, protect, defend and hold each Indemnified Parties harmless under this Agreement; (d) limit any losses arising out of fraud, gross negligence, criminal conduct, intentional misconduct, recklessness or bad faith on the part of the relevant Party (e) limit the Developer’s liability for any type of damage to the extent covered by the proceeds of insurance required hereunder; or (f) limit the amounts expressly provided to be payable by the Parties pursuant to this Agreement.

Related to Exceptions to Waiver

NO WAIVER OF LEGAL RIGHTS The Employer and the Union agree that this program shall not diminish the rights of individual employees under State and/or Federal laws relating to drug and/or alcohol testing.
No waiver of our rights (a) No failure on our part to exercise and no delay on our part in exercising any right or remedy under this agreement will operate as a waiver of such right or remedy, nor will any single or partial exercise of any right or remedy preclude any other or further exercise of such right or remedy or the exercise of any other right or remedy. (b) Any waiver by us of our rights or remedies in respect of any term of this agreement or any breach of this agreement on your part must be in writing and may be given subject to such terms and conditions as we may deem fit and is effective only in the instance and for the purpose for which it is given.
No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.
SUBMISSION TO JURISDICTION; JURY TRIAL WAIVER; WAIVER OF IMMUNITIES In the Deposit Agreement, the Company has (i) waived personal service of process upon it and consented that any service of process in any suit or proceeding arising out of or relating to the Shares or Deposited Securities, the American Depositary Shares, the Receipts or the Deposit Agreement may be made by certified or registered mail, return receipt requested, directed to the Company at its address last specified for notices hereunder, and service so made shall be deemed completed ten (10) days after the same shall have been so mailed, (ii) consented and submitted to the jurisdiction of any state or federal court in the State of New York in which any such suit or proceeding may be instituted, and (iii) agreed that service of process in the manner specified in the Deposit Agreement shall be deemed in every respect effective service of process upon the Company in any such suit or proceeding. EACH PARTY TO THE DEPOSIT AGREEMENT (INCLUDING, FOR AVOIDANCE OF DOUBT, EACH OWNER AND HOLDER) HEREBY IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN ANY SUIT, ACTION OR PROCEEDING AGAINST THE COMPANY AND/OR THE DEPOSITARY DIRECTLY OR INDIRECTLY ARISING OUT OF OR RELATING TO THE SHARES OR OTHER DEPOSITED SECURITIES, THE AMERICAN DEPOSITARY SHARES OR THE RECEIPTS, THE DEPOSIT AGREEMENT OR ANY TRANSACTION CONTEMPLATED HEREIN OR THEREIN, OR THE BREACH HEREOF OR THEREOF, INCLUDING WITHOUT LIMITATION ANY QUESTION REGARDING EXISTENCE, VALIDITY OR TERMINATION (WHETHER BASED ON CONTRACT, TORT OR ANY OTHER THEORY). To the extent that the Company or any of its properties, assets or revenues may have or hereafter become entitled to, or have attributed to it, any right of immunity, on the grounds of sovereignty or otherwise, from any legal action, suit or proceeding, from the giving of any relief in any respect thereof, from setoff or counterclaim, from the jurisdiction of any court, from service of process, from attachment upon or prior to judgment, from attachment in aid of execution or judgment, or other legal process or proceeding for the giving of any relief or for the enforcement of any judgment, in any jurisdiction in which proceedings may at any time be commenced, with respect to its obligations, liabilities or any other matter under or arising out of or in connection with the Shares or Deposited Securities, the American Depositary Shares, the Receipts or the Deposit Agreement, the Company, to the fullest extent permitted by law, hereby irrevocably and unconditionally waives, and agrees not to plead or claim, any such immunity and consents to such relief and enforcement.
No Waiver of Immunities Nothing in this Agreement shall be deemed to waive, modify or amend any legal defense available at law or in equity to County, its past or present officers, employees, or agents or employees, nor to create any legal rights or claim on behalf of any third party. County does not waive, modify, or alter to any extent whatsoever the availability of the defense of governmental immunity under the laws of the State of Texas and of the United States.
No Waiver of Immunity Neither College nor School District waiver or relinquish any immunity or defense on behalf of itself, its trustees, officers, employees, and agents as a result of the execution of this MOU and the performance of the covenants contained herein.
Governing Law; Injunctive Relief; Consent to Jurisdiction; Waiver of Trial by Jury 9.9.1 THIS AGREEMENT AND ANY NON-CONTRACTUAL OBLIGATIONS ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF NEW YORK (WITHOUT REGARD TO ANY PRINCIPLES OF CONFLICTS OF LAW THAT WOULD HAVE THE EFFECT OF GIVING EFFECT TO THE LAWS OF ANOTHER JURISDICTION). 9.9.2 Each party acknowledges that it would be impossible to determine the amount of damages that would result from any breach of any of the provisions of this Agreement and that the remedy at Law for any breach, or threatened breach, of any of such provisions would likely be inadequate and, accordingly, agrees that each other party, in addition to any other rights or remedies which it may have, shall be entitled to seek such equitable and injunctive relief as may be available from any court of competent jurisdiction to compel specific performance of, or restrain any party from violating, any of such provisions. In connection with any action or Proceeding for equitable and injunctive relief permitted hereunder, each party hereby waives the claim or defense that a remedy at Law alone is adequate and, to the maximum extent permitted by Law, agrees to have each provision of this Agreement specifically enforced against it, without the necessity of posting bond or other security against it, and consents to the entry of equitable and injunctive relief against it enjoining or restraining any breach or threatened breach of such provisions of this Agreement. 9.9.3 Each of the parties hereto (i) consents to submit itself to the personal jurisdiction of the Federal District Court for the Southern District of New York or the courts of the State of New York sitting in the Borough of Manhattan in connection with any dispute that arises out of this Agreement or the Sale, (ii) agrees that it will not attempt to deny or defeat such personal jurisdiction by motion or other request for leave from any such court and (iii) agrees that it will not bring any action relating to this Agreement (or any other agreement contemplated hereby) in any court other than the Federal District Court for the Southern District of New York or the courts of the State of New York sitting in the Borough of Manhattan unless venue would not be proper under rules applicable in such courts. Notwithstanding the previous sentence, a party may commence any such action in a court other than the above-named courts solely for the purpose of enforcing an order or judgment issued by one of the above-named courts. 9.9.4 EACH PARTY HEREBY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT TO ANY LITIGATION DIRECTLY OR INDIRECTLY ARISING OUT OF, UNDER OR IN CONNECTION WITH THIS AGREEMENT (OR ANY OTHER AGREEMENT CONTEMPLATED HEREBY).
Governing Law; WAIVER OF TRIAL BY JURY This Lease shall be construed and enforced in accordance with the laws of the State of California. IN ANY ACTION OR PROCEEDING ARISING HEREFROM, LANDLORD AND TENANT HEREBY CONSENT TO (I) THE JURISDICTION OF ANY COMPETENT COURT WITHIN THE STATE OF CALIFORNIA, (II) SERVICE OF PROCESS BY ANY MEANS AUTHORIZED BY CALIFORNIA LAW, AND (III) IN THE INTEREST OF SAVING TIME AND EXPENSE, TRIAL WITHOUT A JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM BROUGHT BY EITHER OF THE PARTIES HERETO AGAINST THE OTHER OR THEIR SUCCESSORS IN RESPECT OF ANY MATTER ARISING OUT OF OR IN CONNECTION WITH THIS LEASE, THE RELATIONSHIP OF LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE, OR ANY EMERGENCY OR STATUTORY REMEDY. IN THE EVENT LANDLORD COMMENCES ANY SUMMARY PROCEEDINGS OR ACTION FOR NONPAYMENT OF BASE RENT OR ADDITIONAL RENT, TENANT SHALL NOT INTERPOSE ANY COUNTERCLAIM OF ANY NATURE OR DESCRIPTION (UNLESS SUCH COUNTERCLAIM SHALL BE MANDATORY) IN ANY SUCH PROCEEDING OR ACTION, BUT SHALL BE RELEGATED TO AN INDEPENDENT ACTION AT LAW.
Governing Law; Consent to Jurisdiction; Waiver of Trial by Jury THIS AGREEMENT AND ANY CLAIM, CONTROVERSY OR DISPUTE ARISING UNDER OR RELATED TO OR IN CONNECTION WITH THE AGREEMENT, THE RELATIONSHIP OF THE PARTIES, AND/OR THE INTERPRETATION AND ENFORCEMENT OF THE RIGHTS AND DUTIES OF THE PARTIES WILL BE GOVERNED BY THE LAWS OF THE STATE OF NEW YORK WITHOUT REGARD TO ANY CONFLICTS OF LAW PRINCIPLES OTHER THAN SECTION 5-1401 OF THE NEW YORK GENERAL OBLIGATIONS LAW. TO THE FULLEST EXTENT PERMITTED UNDER APPLICABLE LAW, EACH OF THE PURCHASER AND THE MORTGAGE LOAN SELLER HEREBY IRREVOCABLY (I) SUBMITS TO THE JURISDICTION OF ANY NEW YORK STATE AND FEDERAL COURTS SITTING IN THE BOROUGH OF MANHATTAN IN NEW YORK CITY WITH RESPECT TO MATTERS ARISING OUT OF OR RELATING TO THIS AGREEMENT; (II) AGREES THAT ALL CLAIMS WITH RESPECT TO ANY ACTION OR PROCEEDING REGARDING SUCH MATTERS MAY BE HEARD AND DETERMINED IN SUCH NEW YORK STATE OR FEDERAL COURTS; (III) WAIVES, TO THE FULLEST POSSIBLE EXTENT, WITH RESPECT TO SUCH COURTS, THE DEFENSE OF AN INCONVENIENT FORUM; (IV) AGREES THAT A FINAL JUDGMENT IN ANY SUCH ACTION OR PROCEEDING SHALL BE CONCLUSIVE AND MAY BE ENFORCED IN OTHER JURISDICTIONS BY SUIT ON THE JUDGMENT OR IN ANY OTHER MANNER PROVIDED BY LAW; AND (V) WAIVES TO THE EXTENT PERMITTED BY APPLICABLE LAW ALL RIGHT TO TRIAL BY JURY IN ANY ACTION, CLAIM, SUIT, PROCEEDING OR COUNTERCLAIM (WHETHER BASED UPON CONTRACT, TORT OR OTHERWISE) RELATING TO OR ARISING OUT OF THIS AGREEMENT.
Exceptions to Limitations These limitations of liability do not apply to breaches of confidentiality obligations, violations of a party’s Intellectual Property Rights by the other party, indemnification obligations, or Customer's payment obligations.

Exceptions to Waiver Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Exceptions to Waiver