WORK JURISDICTION Par.
1. It is agreed by the parties to this Agreement that all work specified in Article IV shall be performed exclusively by Elevator Constructor Mechanics, Elevator Constructor Helpers, Elevator Constructor Apprentices and Elevator Constructor Assistant Mechanics in the employ of the Company.
(a) The handling and unloading of all equipment coming under the jurisdiction of the Elevator Constructor, from the time such equipment arrives at or near the building site, shall be handled and unloaded by the Elevator Constructors. Mechanical equipment such as a fork lift or truck mounted swing boom may be used by the Elevator Constructors. A xxxxxxx, xxxxx or material hoist can be used under the supervision of Elevator Constructors to handle and unload the heavy material described in Par. 5(a). Where unusual conditions are expected to exist prior to delivery of equipment at or near the building site in regard to handling and unloading of equipment in the primary or secondary jurisdiction of the local union, the Company shall contact the Local's Business Representative to make appropriate arrangements for the handling and unloading of such equipment. In areas outside the jurisdiction of the local union, the Company shall contact the Regional Director.
(b) The erecting and assembling of all elevator equipment to wit: electric, hydraulic, steam, belt, dumbwaiters, residence elevators, parking garage elevators (such as Xxxxxx, Pigeon Hole, or similar types of elevators), shuttles, compressed air and handpower, automatic people movers, monorails, airport shuttles and like-named devices used in the transportation of people for short distances of travel (less than 5 miles), as well as vertical reciprocating conveyor systems.
(c) It is understood and agreed that the preassembly of all escalators, moving stairways and link belt carriers that may be done in the factory shall include the following:
1. Truss or truss sections with tracks, drive units, machines, handrail drive sheaves, drive chains, skirts on the incline sections but not curved sections, step chains and steps installed and permanently aligned.
2. Balustrade brackets may be shipped attached but not aligned.
3. Setting of all controllers and all wiring and conduit from the controller. All other work on escalators, moving stairways and link belt carriers shall be performed in the field by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics either before or after the truss or truss sections are joined and/or hoisted and placed in permanent position. This includes any and all work not done in the factory. The erecting and assembly of all theater stage and curtain elevator equipment and guides and rigging thereto, organ consoles and orchestra elevators shall be performed by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics.
(d) All wiring, conduit, and raceways from main line feeder terminals on the controller to other elevator apparatus and operating circuits. Controllers are not to be shipped from the factory with extended wiring attached thereto.
(e) The erecting of all guide rails.
(f) The installation of all grating under the control of the Company. The installation of all counterweight screens, overhead work, either wood or iron, and all material used for mounting of elevator apparatus in machine room, overhead or below.
(g) The drilling of overhead beams for attaching machines, sheaves, kick angles, and all other elevator equipment.
(h) The setting of all templates.
(i) All foundations, either of wood or metal, that should take the place of masonry.
(j) The assembly of all cabs complete.
(k) The installation of all indicators.
(1) The erecting of all electrical or mechanical automatic or semi-automatic gates complete.
FEDERAL JURISDICTIONAL AREAS 33.1. Article 1, § 8, Clause 17 of the United States Constitution provides the authority to Congress to exercise exclusive jurisdiction over areas and structures used for military purposes (Federal Enclaves). Thus, Telecommunications Services to such Federal Enclaves are not subject to the jurisdiction of the Commission. The Parties agree that Services provided within Federal Enclaves are not within the scope of this Agreement. To the extent Sprint has contracts with federal entities that limit or prohibit the ability of CLEC to provide resale or UNEs such contract will govern Telecommunications Services on such Federal Enclave. If the contract with the federal entity provides for the resale or provision of UNEs to provide service on the Federal Enclave, Sprint will provide CLEC with the information regarding the provision of service on the Federal Enclave.
Arbitrator's Jurisdiction The arbitrator shall take such evidence as in his judgment is appropriate for resolution of the dispute; however, he shall confine himself to the issues for arbitration and shall have no authority to determine any other issue not so submitted which is not directly essential to reaching a determination on the dispute at hand. The arbitrator shall have no power to recommend any right or relief for any period of time prior to the effective date of the Agreement under which the grievance was initiated. In those issues wherein the grievant’s relief sought involves back pay or lost wages covering a period of an Employee’s payroll separation due to suspension or discharge, the amount of the award shall be less any unemployment compensation or interim earnings, received by the aggrieved Employee. Second jobs or sources of income which the Employee received while under employment will not be considered interim income and will not be deducted when awarding lost wages or back pay. The decision of the arbitrator shall be submitted in writing to the parties within thirty (30) calendar days of the hearing’s conclusion unless the deadline is mutually extended by the parties. The decision and award of the arbitrator shall be final and binding on the Union, its members, the aggrieved Employee(s) and the CITY. With respect to grievances involving misapplication or misinterpretation of this Agreement, the grievance and arbitration procedure contained in this Article shall be the sole and exclusive remedy available to employees, and the parties hereto as this procedure is intended to supersede all conflicting provisions of the Ohio Revised Code regarding any and all matters subject to the grievance procedures of this Contract or otherwise made subject to this Agreement. With respect to grievances involving disciplinary suspensions, demotions or dismissals the election of remedies, as set forth above, shall be mutually exclusive. Choice of binding arbitration shall thereafter preclude appeal to Civil Service or to Court. Appeal to Civil Service shall preclude access to binding arbitration. With respect to cases of suspension, demotion and discharge, the arbitrator shall decide:
Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties.
17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.
Tax Status Non Jurisdictional Entities Tax Status. Each Party shall cooperate with the other Parties to maintain the other Parties’ tax status. Nothing in this Agreement is intended to adversely affect the tax status of any Party including the status of NYISO, or the status of any Connecting Transmission Owner with respect to the issuance of bonds including, but not limited to, Local Furnishing Bonds. Notwithstanding any other provisions of this Agreement, LIPA, NYPA and Consolidated Edison Company of New York, Inc. shall not be required to comply with any provisions of this Agreement that would result in the loss of tax-exempt status of any of their Tax-Exempt Bonds or impair their ability to issue future tax-exempt obligations. For purposes of this provision, Tax-Exempt Bonds shall include the obligations of the Long Island Power Authority, NYPA and Consolidated Edison Company of New York, Inc., the interest on which is not included in gross income under the Internal Revenue Code. LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.
Applicable Law; Jurisdiction This Agreement shall be governed by and interpreted in accordance with the laws of the State of New Jersey without regard to the principles of conflict of laws. The parties further agree that any action between them shall be heard in Xxxxxx County, New Jersey, and expressly consent to the jurisdiction and venue of the Superior Court of New Jersey, sitting in Xxxxxx County and the United States District Court for the District of New Jersey sitting in Newark, New Jersey for the adjudication of any civil action asserted pursuant to this Paragraph.
Jurisdiction, Etc (a) Each party hereto hereby irrevocably and unconditionally agrees that it will not commence any action, litigation or proceeding of any kind or description, whether in law or equity, whether in contract or in tort or otherwise, against the Administrative Agent, any Lender, any LC Issuing Bank, or any Related Party of the foregoing in any way relating to this Agreement or any other Loan Document or the transactions relating hereto or thereto, in any forum other than the courts of the State of New York sitting in the Borough of Manhattan in New York City, and of the United States District Court of the Southern District of New York sitting in the Borough of Manhattan in New York City, and any appellate court from any thereof, and each of the parties hereto irrevocably and unconditionally submits to the jurisdiction of such courts and agrees that all claims in respect of any such action, litigation or proceeding may be heard and determined in such New York State court or, to the fullest extent permitted by applicable law, in such federal court. Each party hereto agrees that a final judgment in any such action, litigation or proceeding shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law.
(b) The Borrower irrevocably and unconditionally waives, to the fullest extent permitted by Applicable Law, any objection that it may now or hereafter have to the laying of venue of any action or proceeding arising out of or relating to this Agreement or any other Loan Document in any court referred to in paragraph (a) of this Section. Each of the parties hereto hereby irrevocably waives, to the fullest extent permitted by applicable law, the defense of an inconvenient forum to the maintenance of such action or proceeding in any such court.
(c) Each party hereto irrevocably consents to service of process in the manner provided for notices in Section 8.02. Nothing in this Agreement will affect the right of any party hereto to serve process in any other manner permitted by Applicable Law.
Non-Jurisdictional Entities LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.
Exclusive English jurisdiction Subject to Clause 30.3, the courts of England shall have exclusive jurisdiction to settle any disputes which may arise out of or in connection with this Agreement.
TERRITORIAL JURISDICTION The Territorial Jurisdiction of this Collective Agreement is the whole area within the boundaries of the Province of Ontario.
