Extension for Delay due to Railways Sample Clauses

Extension for Delay due to Railways. In the event of any failure or delay by the Railway to hand over the Contractor possession of the lands necessary for the execution of the works or to give the necessary notice to commence the works or to provide the necessary drawings or instructions or any other delay caused by the Railway due to any other cause whatsoever, then such failure or delay shall in no way affect or vitiate the contract or alter the character thereof or entitle the Contractor to damages or compensation therefor, but in any such case, the Railway may grant such extension or extensions of the completion date as may be considered reasonable. The Contractor shall indicate the period for which the work is likely to be delayed and shall seek extension of time as may be considered necessary under clause 17A(i) or/and 17A(ii) or/ and 17A(iii) above, as soon as the cause thereof shall arise and, in any case, not less than 15 days before the expiry of the date fixed for completion of the works. The Engineer shall consider the same and shall grant and communicate such extension of time as in his opinion is reasonable having regard to the nature and period of delay and the type and quantum of work affected thereby. No other compensation shall be payable for works so carried forward to the extended period of time; the same rates, terms and conditions of contract being applicable, as if such extended period of time was originally provided in the original contract itself. The non-submission of request for extension or submission of request within less than 15 days before the expiry of the date fixed for completion of the works, shall make him ineligible for extension under these sub clauses, subject to final decision of Engineer. [ACS dated 14.07.2022] 17B Extension of Time with Liquidated Damages (LD) for delay due to Contractor: The time for the execution of the work or part of the works specified in the contract documents shall be deemed to be the essence of the contract and the works must be completed not later than the date(s) as specified in the contract. If the Contractor fails to complete the works within the time as specified in the contract for the reasons other than the reasons specified in Clause 17 and 17A, the Railway may, if satisfied that the works can be completed by the Contractor within reasonable short time thereafter, allow the Contractor for further extension of time (Proforma at Annexure-VII) as the Engineer may decide. On such extension the Railway will be entitled wit...
Sample 1
AutoNDA by SimpleDocs
Extension for Delay due to Railways. In the event of any failure or delay by the Railway to hand over the Contractor possession of the lands necessary for the execution of the works or to give the necessary notice to commence the works or to provide the necessary drawings or instructions or any other delay caused by the Railway due to any other cause whatsoever, then such failure or delay shall in no way affect or vitiate the contract or alter the character thereof or entitle the contractor to damages or compensation therefor, but in any such case, the Railway may grant such extension or extensions of the completion date as may be considered reasonable
Sample 1

Related to Extension for Delay due to Railways

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • TERM, TERMINATION & SUSPENSION The Company may terminate this Agreement with You at any time for any reason, with or without cause. The Company specifically reserves the right to terminate this Agreement if You violate any of the terms outlined herein, including, but not limited to, violating the intellectual property rights of the Company or a third party, failing to comply with applicable laws or other legal obligations, and/or publishing or distributing illegal material. If You have registered for an account with Us, You may also terminate this Agreement at any time by contacting Us and requesting termination. At the termination of this Agreement, any provisions that would be expected to survive termination by their nature shall remain in full force and effect.

  • Extension of Probationary Period III.6.3.3.1 Notwithstanding the various provisions above which define a maximum period of probationary service, a member who has had a pregnancy leave during her probationary period under IV.13.6.2

  • Termination for Non-Appropriation The continuation of this Contract beyond the current fiscal year is subject to and contingent upon sufficient funds being appropriated, budgeted, and otherwise made available by the City. The City may terminate this Contract, and Contractor waives any and all claim(s) for damages, effective immediately upon receipt of written notice (or any date specified therein) if for any reason the City’s funding from State and/or federal sources is not appropriated or is withdrawn, limited, or impaired.

  • Suspension; Termination If Borrower voluntarily suspends its business or, the partnership is dissolved or terminated, other than a technical termination of the partnership for tax purposes.

  • Termination for Nonpayment In the event of the nonpayment of fees owed to DSI, DSI shall provide written notice of delinquency to all parties to this Agreement. Any party to this Agreement shall have the right to make the payment to DSI to cure the default. If the past due payment is not received in full by DSI within one month of the date of such notice, then DSI shall have the right to terminate this Agreement at any time thereafter by sending written notice of termination to all parties. DSI shall have no obligation to take any action under this Agreement so long as any payment due to DSI remains unpaid.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!