Extensions of Time - Extension Event. 26.4.1 If the Concessionaire believes that the Works will not be carried out in accordance with the Works Timeline, then without prejudice to Clause 26.7 (Delays in Works - Contractual Penalties):
Extensions of Time - Extension Event Sample Clauses
Related to Extensions of Time - Extension Event
Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
217 Extension Deposits In the event of Contract Term Extension, Forest Service shall divide the difference between Current Contract Value as of the start of any Contract Term Extension and the credit balance of any deposit made pursuant to B4.213 by the number of whole months remaining in Normal Operating Season(s) within the extension period to determine the amount of each “Extension Deposit.” Purchaser shall make the initial Extension Deposit prior to Forest Service executing the contract modifica- tion. In response to Forest Service billing under B4.21, Purchaser shall make advance cash deposits. Such de- posits shall at least equal each Extension Deposit re- quired for each whole month remaining in Normal Operat- ing Season(s) during the extension period. Extension De- posits shall be due by the last day of each month during Normal Operating Season whether or not the volume that is covered by such deposits has been Scaled. Due dates for Extension Deposits during the exten- sion period may be delayed when Purchaser earns Con- tract Term Adjustment if Termination Date, as adjusted, results in one or more additional complete months within Normal Operating Season(s).
Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.
No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Extension Terms County may, at its sole option, extend the term of this Agreement beyond the Initial Term for up to ___ additional one-year terms at the same rates and under the same terms provided for herein (each such period being an “Extension Term”). County shall notify Contractor of its election for an Extension Term(s) as provided for in §6.
Extension Term Provided Lessee is not in default in the performance of any term or condition of this Lease, Lessee shall have the option to extend this Lease for two (2) additional terms of five (5) years per term, commencing with the expiration of the first or additional term, upon the following conditions:
Interim Extension Amendment a. Prior to or on the expiration date of this Contract, the Parties agree that this Contract can be extended as provided under this Section.
