Failure to Agree If the Contractor claims entitlement to a change in the Contract, and the Department does not agree that any action or event has occurred to justify any change in time or compensation, or if the parties fail to agree upon the appropriate amount of the adjustment in time or compensation, the Department will unilaterally make such changes, if any, to the Contract, as it determines are appropriate pursuant to the Contract. The Contractor shall proceed with the Work and the Department's directives, without interruption or delay, and shall make a claim as provided in Article 12. Failure to proceed due to a dispute over a change request shall constitute a material breach of the Contract and entitle the Department to all available remedies for such breach, including, without limitation, termination for default.
Failure to Notify If Contractor fails to specify in writing any problem or circumstance that materially affects the costs of its delivery of services or products, including a material breach by the Department, about which Contractor knew or reasonably should have known with respect to the period during the term covered by Contractor's status report, Contractor shall not be entitled to rely upon such problem or circumstance as a purported justification for an increase in the price for the agreed upon scope.
Failure to Fulfill Conditions In the event that either of the parties hereto determines that a condition to its respective obligations to consummate the transactions contemplated hereby cannot be fulfilled on or prior to the termination of this Agreement, it will promptly notify the other party.
Failure to Supply 4.2.1 If Company becomes aware that a Supply Interruption is reasonably likely to occur, Company shall promptly notify AbbVie by telephone or by written notification and shall provide AbbVie with the opportunity to meet in person or by teleconference to discuss the details to the extent they are known by Company.
4.2.2 In the event that Company is unable, or notifies AbbVie that it is unable or otherwise receives notice from its CMO that it will be unable to supply, for any reason, except for a Force Majeure Event, to supply Product in accordance with the quantities and/or delivery dates specified by AbbVie for such Product via Purchase Orders, Company shall have a period of *** days or such longer time as necessary so long as Company is using commercially reasonable efforts to cure such interruption to supply, during which time Company will prioritize AbbVie Purchase Orders of Product over Company or other customer orders. If such interruption to supply continues after such sixty (60) day period, AbbVie may, in its sole discretion: (a) cancel outstanding Purchase Orders with Company; (b) require Company to supply the undelivered Product at a future date agreed upon by the Parties; or (c) at Company’s sole expense, manufacture or have manufactured by a Third Party designated and qualified by AbbVie such quantity of ribavirin as AbbVie may reasonably determine with notice to Company as will meet AbbVie’s worldwide requirements in light of such interruption to supply. AbbVie shall be entitled to receive from Company *** % of AbbVie’s cover damages, comprising cost differences between the Product’s cost and the replacement product’s cost, and reasonable costs associated with procuring replacements for the Product, until such time as Company is capable of resuming its supply obligations under this Agreement. Upon Company’s resolution of the interruption to supply to the reasonable satisfaction of AbbVie, AbbVie shall be required to resume purchasing the Applicable Percentage of AbbVie Product Requirements from Company but shall be excused from purchasing that portion attributable to the permitted purchases from the Third Party manufacturer under Section 4.2.2(c).
Rights and Remedies Cumulative; Delay or Omission Not Waiver (a) Except as otherwise provided in Section 2.07, all powers and remedies given by this Article to the Trustee or to the Securityholders shall, to the extent permitted by law, be deemed cumulative and not exclusive of any other powers and remedies available to the Trustee or the holders of the Securities, by judicial proceedings or otherwise, to enforce the performance or observance of the covenants and agreements contained in this Indenture or otherwise established with respect to such Securities.
(b) No delay or omission of the Trustee or of any holder of any of the Securities to exercise any right or power accruing upon any Event of Default occurring and continuing as aforesaid shall impair any such right or power, or shall be construed to be a waiver of any such default or an acquiescence therein; and, subject to the provisions of Section 6.04, every power and remedy given by this Article or by law to the Trustee or the Securityholders may be exercised from time to time, and as often as shall be deemed expedient, by the Trustee or by the Securityholders.
Failure to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
Failure to Act Not a Defense The failure of the Company (including its Board of Directors or any committee thereof, independent legal counsel, or stockholders) to make a determination concerning the permissibility of the payment of Indemnifiable Amounts or the advancement of Indemnifiable Expenses under this Agreement shall not be a defense in any action brought under Section 10(a) above, and shall not create a presumption that such payment or advancement is not permissible.
Failure to Act Within Time Limits If the Griever or the Union fails to process a grievance to the next step in the grievance procedure within the time limits specified, they shall not be deemed to have prejudiced their position on any future grievance.
Failure to Defend If the Indemnifying Party, within a reasonable time after notice of any such Claim, fails to defend such Claim actively and in good faith, the Indemnified Party will (upon further notice) have the right to undertake the defense, compromise or settlement of such Claim or consent to the entry of a judgment with respect to such Claim, on behalf of and for the account and risk of the Indemnifying Party, and the Indemnifying Party shall thereafter have no right to challenge the Indemnified Party's defense, compromise, settlement or consent to judgment.
Amendments in Writing; No Waiver; Cumulative Remedies (a) None of the terms or provisions of this Guaranty may be waived, amended, supplemented or otherwise modified except by a written instrument executed by the Guarantor and the Buyer, provided that any provision of this Guaranty may be waived by the Buyer.
(b) The Buyer shall not by any act (except by a written instrument pursuant to Section 14(a) hereof), delay, indulgence, omission or otherwise be deemed to have waived any right or remedy hereunder or to have acquiesced in any Default or Event of Default or in any breach of any of the terms and conditions hereof. No failure to exercise, nor any delay in exercising, on the part of the Buyer, any right, power or privilege hereunder shall operate as a waiver thereof. No single or partial exercise of any right, power or privilege hereunder shall preclude any other or further exercise thereof or the exercise of any other right, power or privilege. A waiver by the Buyer of any right or remedy hereunder on any one occasion shall not be construed as a bar to any right or remedy which the Buyer would otherwise have on any future occasion.
(c) The rights and remedies herein provided are cumulative, may be exercised singly or concurrently and are not exclusive of any other rights or remedies provided by law.
