Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.
Site Plan It is Licensee’s responsibility before signing this Agreement to ensure that the Site Plan correctly shows the work that Licensee intends to perform, that the Site Plan correctly shows all improvements and equipment that Licensee intends be located on the Use Areas, that the Site Plan shows no work, improvements or equipment outside the Exclusive Areas and Shared Areas properly depicted and labeled on the Boundary Plan, and that all work, improvements and equipment is encompassed within the purposes enumerated in the Standard Terms for that particular Exclusive Area or Shared Area. Any work, improvements or equipment not conforming to all the foregoing is prohibited, even if it is clearly shown on the Site Plan or discussed in the Standard Terms. Any refinement or other change to the Site Plan after Licensor executes this Agreement is void unless Licensee obtains Licensee’s approval of the change pursuant to the plans approval processes set out in the Standard Terms and pursuant to all applicable regulatory requirements.
Final Acceptance When the Project/Service or any portion thereof, as designated by the COUNTY, is ready for its intended use, the COUNTY and any other invited parties shall make an inspection of the Project/Service, to verify its completeness and develop a punch list of items needing completion or correction before final payment will be made. CONTRACTOR shall have ten (10) calendar days to correct all deficiencies. An eighty-dollar ($80.00) re-inspection fee shall be applied for the third inspection and any required re-inspection thereafter. The COUNTY shall have the right to exclude CONTRACTOR from those portions of the work designated as complete after the inspection; provided, however, that CONTRACTOR will have reasonable access for the time allotted by the COUNTY to complete or correct items on the punch list. When the work provided for under this Agreement has been completely performed by CONTRACTOR, and the final inspection has been made by the COUNTY, a final invoice will be prepared by the CONTRACTOR. The amount of this invoice, less any sums that may have been deducted or retained under the provisions of this Agreement, will be paid to CONTRACTOR in accordance with this Agreement, and after CONTRACTOR has agreed in writing to accept the balance due, as determined by the COUNTY, as full settlement of the account under the contract and of all claims in connection therewith. Occupancy by the COUNTY alone does not constitute final acceptance.
Inspection; Acceptance The Contractor (immixTechnology, Inc.) can only, and shall only tender for acceptance those items that substantially conform to the software manufacturer’s (“Qualtrics”) published specifications. Therefore, items delivered shall be considered accepted upon delivery. The Government reserves the right to inspect or test any supplies or services that have been delivered. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-(1) Within the warranty period; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Additional Space Commencing on May 1, 2001, Sublessor herein grants unto the Sublessee a Right of First Refusal on any space that shall be and/or becomes available in the building during the remaining Term of this Sublease. Prior to May 1, 2001 and thereafter prior to the first day of May of any calendar year during the remaining Term hereof, Sublessor shall notify Sublessee by written notice of the availability of any such space in the building. Should Sublessee desire to exercise its Right of First Refusal and sublease such available space, Sublessee must notify Sublessor in writing of its desire to sublease the available space within seven (7) calendar days of Sublessee's receipt of Landlord's notice of availability. Within thirty (30) days of the receipt of Sublessee's notice exercising the right to sublease such available space, Sublessee and Sublessor shall enter into an amendment of this agreement setting forth the terms under which the additional space is subleased to Sublessee. The Base Rental shall be at a rental mutually agreed between Sublessee and Sublessor. Failure by Sublessee to exercise its Right of First Refusal within said seven (7) calendar day period, or if exercised, failure to enter into an amendment of this agreement within thirty (30) days of Sublessor's receipt of Sublessee's notice, shall be deemed a waiver of such right and Sublessor shall thereafter be free of any obligation under this Article 2.04 for a period of 12 months. Any exercise by Sublessee of this Right of First Refusal shall be for a minimum of 5,000 rental square feet.
Order Acceptance Xxxxxxx’x acceptance of the Order and consequent agreement to the Contract by either: (a) delivering the Goods, Services, or Digital Services; or
WORK LETTER This Lease is supplemented by that certain Work Letter of even date executed by Lessor and Lessee, attached hereto as Exhibit C, and incorporated herein by this reference.