Limited Scope The following are excluded from binding arbitration under this Agreement: claims for workers’ compensation benefits or unemployment benefits; replevin; and claims for which a binding arbitration agreement is invalid as a matter of law.
CONTRACT SCOPE Pursuant to this Contract, Contractor is authorized to sell and provide only those Goods and/or Services set forth in Exhibit A – Included Goods/Services for the prices set forth in Exhibit B – Prices for Goods/Services. Contractor shall not represent to any Purchaser under this Contract that Contractor has contractual authority to sell or provide any Goods and/or Services beyond those set forth in Exhibit A – Included Goods/Services.
Service Scope The following Services are covered by this Agreement; o Manned telephone support o Monitored email support o Remote assistance using Remote Desktop and a Virtual Private Network where available o Planned or Emergency Onsite assistance (extra costs apply) o Monthly system health check
Project Scope The physical scope of the Project shall be limited to only those capital improvements as described in Appendix A of this Agreement. In the event that circumstances require a change in such physical scope, the change must be approved by the District Committee, recorded in the District Committee's official meeting minutes, and provided to the OPWC Director for the execution of an amendment to this Agreement.
Laboratory Testing All laboratories selected by UPS Freight for analyzing Controlled Substances Testing will be HHS certified.
Years Experience Company years experience in this category? This is an evaluation criterion worth a maximum of 10 points. See RFP for more information. (If applicable, vendor should download the Reseller/Dealers spreadsheet from the Attachments section, fill out the f orm and submit the document in the ”Response Attachments” RESELLERS section. EXAMPLE: BIGmart is a reseller of ACME brand televisions. If ACME were a TIPS awarded vendor, then ACME woul d list BIGmart as a reseller.
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
General Scope of Services Contractor promises and agrees to furnish all labor, materials, tools, equipment, services, and incidental and customary work necessary to fully and adequately supply professional services, as more particularly described in Exhibit B (Statement of Work and Misc. Documents) attached hereto and incorporated herein by reference (collectively “Services”). All Services shall be subject to, and performed in accordance with, this Contract, the exhibits attached hereto and incorporated herein by reference, and all applicable local, state and federal laws, rules and regulations.
Attachment A, Scope of Services The scope of services is amended as follows:
Change of Scope (i) The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/ alterations to the Works (“Change of Scope”) within a period of six months counted from the Appointed Date. Upon the Authority making its intention known to the Contractor for the specific Change of Scope, be it positive or negative, the Contractor shall submit his proposal for the said Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
(ii) Provided that any such Change of Scope, excluding major structures (e.g. Major Bridge/ ROB/ RUB/ Flyover/ elevated road of more than 50 m length) may be required and agreed to be executed between the parties beyond the period of six months of the Appointed Date but before expiry of 50% of the original Scheduled Construction Period of the Project Highway, subject to the condition that it shall not entail any claims (e.g. Extension of Time/ Prolongation related claims), against the Authority.
(iii) The Change of Scope shall mean the following:
(a) change in specifications of any item of Works;
(b) omission of any work from the Scope of the Project except under Clause 8.3 (iii); provided that, subject to Clause 13.5, the Authority shall not omit any Work under this Clause in order to get it executed by any other authority; and / or
(c) any additional Work, Plant, Materials or services which are not included in the Scope of the Project, including any associated Tests on completion of construction.
