For Resident Services During Construction Sample Clauses

For Resident Services During Construction. OWNER shall pay ENGINEER for the actual time expended and expenses incurred in the performance of resident services during construction as outlined in Section 1.5 at the labor rates and non-labor rates shown in Exhibit C, and according to the phases of work shown in Exhibit D. However, it is understood that the duration of construction is subject to delays beyond the control of the ENGINEER and the actual time required for resident services may be more or less than the time estimated by the ENGINEER and reflected in the fee specified above, therefore delays in construction may warrant the issuance of an amendment to the contract at a later date.
Sample 1
AutoNDA by SimpleDocs
For Resident Services During Construction. OWNER shall pay ENGINEER for the actual time expended and expenses incurred in the performance of resident services during construction as outlined in Section 1.5 at the labor rates and non-labor rates shown in Exhibit A, and according to the phases of work and not to exceed cost estimate shown in Exhibit B, the scope of work for which shall not be changed, and the cost for which shall not be exceeded, except by formal written amendment. However, it is understood that the duration of construction is subject to delays beyond the control of the ENGINEER and the actual time required for resident services may be more or less than the time estimated by the ENGINEER and reflected in the fee specified above, therefore delays in construction may warrant the issuance of an amendment to the contract at a later date.
Sample 1

Related to For Resident Services During Construction

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Services and Duties of the Distributor A. The Distributor agrees to sell Shares on a best efforts basis as agent for the Trust upon the terms and at the current offering price (plus sales charge, if any) described in the Prospectus. As used in this Agreement, the term “Prospectus” shall mean the current prospectus, including the statement of additional information, as both may be amended or supplemented, relating to the Fund and included in the currently effective registration statement (the “Registration Statement”) of the Trust filed under the Securities Act of 1933, as amended (the “1933 Act”) and the 1940 Act. The Trust shall in all cases receive the net asset value per Share on all sales. If a sales charge is in effect, the Distributor shall remit the sales charge (or portion thereof) to broker-dealers who have sold Shares, as described in Section 2(G), below. In no event shall the Distributor be entitled to all or any portion of such sales charge. B. During the continuous public offering of Shares, the Distributor will hold itself available to receive orders, satisfactory to the Distributor, for the purchase of Shares and will accept such orders on behalf of the Trust. Such purchase orders shall be deemed effective at the time and in the manner set forth in the Prospectus. C. The Distributor, with the operational assistance of the Trust’s transfer agent, shall make Shares available for sale and redemption through the National Securities Clearing Corporation’s Fund/SERV System. D. The Distributor acknowledges and agrees that it is not authorized to provide any information or make any representations other than as contained in the Prospectus and any sales literature specifically approved by the Trust. E. The Distributor agrees to cooperate with the Trust or its agent in the development of all proposed advertisements and sales literature relating to the Fund. The Distributor agrees to review all proposed advertisements and sales literature for compliance with applicable laws and regulations, and shall file with appropriate regulators those advertisements and sales literature it believes are in compliance with such laws and regulations. The Distributor agrees to furnish to the Trust any comments provided by regulators with respect to such materials and to use its best efforts to obtain the approval of the regulators to such materials. F. The Distributor, at its sole discretion, may repurchase Shares offered for sale by shareholders of the Fund. Repurchase of Shares by the Distributor shall be at the price determined in accordance with, and in the manner set forth in, the Prospectus. At the end of each business day, the Distributor shall notify the Trust and its transfer agent, by any appropriate means, of the orders for repurchase of Shares received by the Distributor since the last report, the amount to be paid for such Shares and the identity of the shareholders offering Shares for repurchase. The Trust reserves the right to suspend such repurchase right upon written notice to the Distributor. The Distributor further agrees to act as agent for the Trust to receive and transmit promptly to the Trust’s transfer agent, shareholder requests for redemption of Shares. G. The Distributor may, in its discretion, enter into agreements with such qualified broker-dealers as it may select, in order that such broker-dealers also may sell Shares of the Fund. The form of any dealer agreement shall be approved by the Trust. To the extent there is a sales charge in effect, the Distributor shall pay the applicable sales charge (or portion thereof), or allow a discount, to the selling broker-dealer, as described in the Prospectus. H. The Distributor shall devote its best efforts to effect sales of Shares of the Fund but shall not be obligated to sell any certain number of Shares. I. The Distributor shall prepare reports for the Board regarding its activities under this Agreement as from time to time shall be reasonably requested by the Board, including reports regarding the use of any 12b-1 payments received by the Distributor. J. The Distributor agrees to advise the Trust promptly in writing of the initiation of any proceedings against it by the SEC or its staff, the NASD or any state regulatory authority. K. The Distributor shall monitor amounts paid under Rule 12b-1 plans and pursuant to sales loads to ensure compliance with applicable NASD rules.

  • Services and Duties of USBFS USBFS shall provide the following transfer agent and dividend disbursing agent services to the Fund: A. Receive and process all orders for the purchase, exchange, transfer, and/or redemption of Fund shares in accordance with Rule 22c-1 under the 1940 Act, other applicable regulations, and as specified in the Fund's prospectus (the "Prospectus”). B. Process purchase and redemption orders with prompt delivery, where appropriate, of payment and supporting documentation to the shareholder based on the shareholder’s or the Trust’s custodian instructions, and record the appropriate number of shares being held in the appropriate shareholder account. C. Process redemption requests received in good order and, where relevant, deliver appropriate documentation to the Trust's custodian. D. Pay proceeds upon receipt from the Trust's custodian, where relevant, in accordance with the instructions of redeeming shareholders. E. Process transfers of shares in accordance with the shareholder's instructions, after receipt of appropriate documentation from the shareholder as specified in the Prospectus. F. Prepare and transmit payments, or apply reinvestments for income dividends and capital gains distributions declared by the Trust with respect to a Fund, after deducting any amount required to be withheld by any applicable laws, rules and regulations and in accordance with shareholder instructions. G. Serve as the Fund’s agent in connection with systematic plans including, but not limited to, systematic investment plans, systematic withdrawal plans, and systematic exchange plans. H. Make changes to shareholder records, including, but not limited to, address and plan changes (e.g., systematic investment and withdrawal, dividend reinvestment). I. Handle load and multi-class processing, including rights of accumulation and purchases by letters of intent in accordance with the Prospectus. J. Record the issuance of shares of each Fund and maintain, pursuant to Rule 17Ad-10(e) promulgated under the Securities Exchange Act of 1934, as amended (the "Exchange Act"), a record of the total number of shares of each Fund which are authorized, issued and outstanding. K. Prepare ad-hoc reports as necessary at prevailing rates. L. Mail shareholder reports and Prospectuses to current shareholders. M. Prepare and file U.S. Treasury Department Forms 1099 and other appropriate information returns required with respect to dividends and distributions for all shareholders. N. Provide shareholder account information upon shareholder or Trust requests and prepare and mail confirmations and statements of account to shareholders for all purchases, redemptions and other confirmable transactions as agreed upon with the Trust. O. Mail and/or obtain shareholders’ certifications under penalties of perjury and pay on a timely basis to the appropriate federal or state authorities any taxes to be withheld on dividends and distributions paid by the Trust, all as required by applicable federal and state tax laws and regulations. P. Answer correspondence from shareholders, securities brokers and others relating to USBFS’ duties hereunder within required time periods established by applicable regulation. Q. Reimburse the Fund for all material losses resulting from “as of” processing errors for which USBFS is responsible in accordance with the “as of” processing guidelines set forth on Exhibit B hereto. R. Calculate average assets held in shareholder accounts for purposes of paying Rule 12b-1 and/or shareholder servicing fees as directed by a Fund S. Provide service and support to financial intermediaries including but not limited to trade placements, settlements, and corrections.

  • Access to Services Subject to and in accordance with the terms of this Agreement, including any Schedules, Company grants You a non-exclusive, non-sublicensable, nontransferable, non-assignable, revocable license for the term of this Agreement to access and use the Services. Services may only be used by Your Users for internal business purposes only. You agree to comply with the terms and conditions of this Agreement, including any Schedules, and with all applicable Company procedures and policies that further define use of the Services. You acknowledge and agree that the actions of any of Your Users with respect to the Services will be deemed to be actions by You and that any breach by any of Your Users of the terms of this Agreement, including any Schedule, will be deemed to be a breach by You.

  • Manager’s Use of the Services of Others The Manager may (at its cost except as contemplated by Paragraph 4 of this Agreement) employ, retain or otherwise avail itself of the services or facilities of other persons or organizations for the purpose of providing the Manager or the Corporation or Fund, as appropriate, with such statistical and other factual information, such advice regarding economic factors and trends, such advice as to occasional transactions in specific securities or such other information, advice or assistance as the Manager may deem necessary, appropriate or convenient for the discharge of its obligations hereunder or otherwise helpful to the Corporation or Fund, as appropriate, or in the discharge of Manager's overall responsibilities with respect to the other accounts which it serves as investment manager.

  • Sub-adviser’s Use of the Services of Others The Sub-Adviser may (at its cost except as contemplated by Section 5 of this Agreement) employ, retain, or otherwise avail itself of the services or facilities of other persons or organizations for the purpose of obtaining such statistical and other factual information, such advice regarding economic factors and trends, such advice as to occasional transactions in specific securities, or such other information, advice, or assistance as the Sub-Adviser may deem necessary, appropriate, or convenient for the discharge of its obligations hereunder or otherwise helpful to the Sub-Adviser, as appropriate, or in the discharge of Sub-Adviser's overall responsibilities with respect to the other accounts that it serves as investment manager or counselor, provided that the Sub-Adviser shall at all times retain responsibility for making investment recommendations with respect to the Fund.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!