ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by the City, Engineer shall furnish, or obtain from others, Additional Services that may be required because of significant changes in the scope, extent or character of the portions of the Project designed or specified by the Engineer, as defined in Exhibit “A”. These Additional Services, plus reimbursable expenses, will be paid for by the Owner on the basis set forth in Exhibit “A,” up to the amount authorized in writing by the City.
ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by OWNER, ENGINEER shall provide, or obtain from other qualified persons or firms, Additional Services which are not included as part of the Basic Services specified in Section 1. Additional Services shall include, but are not limited to, the following:
2.1. Services resulting from significant changes in the general scope, extent or character of the Project designed or specified by ENGINEER or its design including, but not limited to, changes in size, complexity, OWNER's schedule, character of construction or method of financing; and revising previously accepted studies, reports, design documents or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to the preparation of such studies, reports or documents, or are due to any other causes beyond ENGINEER’s control.
2.2. Preparing documents for alternate bids requested by OWNER for Contractor's work which is not executed or documents for out-of-sequence work.
2.3. Services resulting from the award of more than one separate prime contract for construction, materials or equipment for the Project unless multiple awards were contemplated and included as part of Basic Services in Section 1.
2.4. Assistance in connection with rebidding or renegotiating contracts for construction which involve modifying the Contract Documents to revise the Project's general scope, extent or character as necessary to reduce or increase the Construction Cost to bring it within the cost limit.
2.5. Preparing to serve or serving as a consultant or witness for OWNER in any litigation, arbitration or other legal or administrative proceeding involving the Project.
2.6. Services in making revisions to Contract Documents occasioned by the acceptance of substitutions proposed by Contractor; and services after the award of the construction contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor.
2.7. Services resulting from significant delays in Project schedule which occurred through no fault of ENGINEER.
2.8. Additional or extended services during construction made necessary by (a) work damaged by fire or other cause during construction; (b) a significant amount of defective, neglected or delayed work of Contractor or supplier; (c) protracted or extensive assistance in the startup or utilization of any equipment or system; (d) acceleration of the progr...
ADDITIONAL SERVICES OF ENGINEER. Additional Services of Engineer, which may be required by the CITY, shall be based on the actual hours Agreement for Professional Services APAI Project No. 0000-000-00 and costs in accordance with Exhibit B-1. No work shall be undertaken as an Additional Service of Engineer without specific written authorization from the CITY. All direct expenses, including mileage, travel and lodging expenses, but excluding subcontract expenses, applied to the Additional Services of Engineer, shall be paid at invoice or internal office cost plus a ten percent (10%) service charge. Subcontract expenses shall be paid at direct cost plus a ten percent (10%) service charge. All sales, use, value added, business transfer, gross receipts, or other similar taxes will be added to ENGINEER's compensation when invoicing CITY.
ADDITIONAL SERVICES OF ENGINEER. As noted below, the ENGINEER is hereby authorized to perform the following additional services as outlined in Exhibit A – Paragraphs 2.01 and 2.02: Included Excluded a. Design Survey x. Xxxxx or Loan Application c. Storm Water Pollution Prevention Plan d. Environmental Assessment e. Environmental Information Document f. Resident Project Representative Services g. Construction Survey (Baselines and Benchmarks) h. Geotechnical Investigation i. Materials Testing j. Analytical Testing k. Reimbursable Expenses (Mileage, Printing, Postage & etc.) l. Easement or Boundary Surveys m. Easement or Boundary Descriptions n. Land Acquisition Services o. TxDOT Utility Installation Request Applications p. Operation and Maintenance Manual q. Other: Part-Time Resident Project Representative Services r. Other: s. Other: t. Other: u. Other: v. Other: w. Other:
ADDITIONAL SERVICES OF ENGINEER. At the request of the Owner, the Engineer can provide additional services, either directly or through its affiliates, at regular hourly rates for such work plus out of pocket expenses. Such work may include items not otherwise provided for by this agreement. To assure an understanding of matters related to our mutual responsibilities, these terms and conditions for services are made a part of this agreement for our services:
ADDITIONAL SERVICES OF ENGINEER. Extra Services of the Engineer will be paid only with written prior authorization by Xxxxxxxx.
ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by OWNER, ENGINEER shall furnish or obtain from others Additional Services of the types listed in Appendix "E", attached to this Agreement, and made an integral part hereof.
ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by Owner, Engineer shall provide, or obtain from other qualified persons or firms, Additional Services that are not included as part of the Basic Services of Engineer. Additional Services may include:
2.1 Services resulting from significant changes in the general scope, extent or character of the Project designed or specified by Engineer or its design including, but not limited to, changes in size, complexity, Owner’s schedule, means and methods of operation, character of construction or method of financing; and revising previously accepted studies, reports, design documents or Contract Documents when such revisions are required by changes in laws, rules, regulations, ordinances, codes or orders enacted subsequent to the preparation of such studies, reports or documents, or are due to any other causes beyond Engineer’s control.
2.2 Unless specifically set forth in Basic Services of Engineer, Basic Services do not include costs of the Engineer for required or requested assistance to support, prepare, document, bring, defend, or assist in litigation or administrative proceedings taken or defended by the Owner, for this Project. All such services required or requested of the Engineer by the Owner, except for suits or claims between the parties to this Agreement, will be reimbursed as may be mutually agreed, and payment for such services shall be in accordance with Section 5.
2.3 Services resulting from significant delays or work stoppages in Project schedule which occurred through no fault of Engineer.
2.4 Additional Services in connection with the Project, including services which are to be furnished by Owner in accordance with Section 3 and services not otherwise provided for in Basic Services as specified in Section 1 of this Agreement.
ADDITIONAL SERVICES OF ENGINEER. If authorized in writing by the MEDC, Engineer shall furnish, or obtain from others, Additional Services that may be required because of significant changes in the scope, extent or character of the portions of the Project designed or specified by the Engineer, as defined in Attachment “A.” These Additional Services, plus reimbursable expenses, will be paid for by the Owner on the basis set forth in Attachment “A,” up to the amount authorized in writing by the MEDC.
ADDITIONAL SERVICES OF ENGINEER. Owner shall pay Engineer for Additional Services of Engineer rendered under Section 2. Fees shall be paid per Section 5 of the Agreement. Compensation for Additional Services actually completed shall be paid on a cost reimbursable basis in an amount not to be negotiated if such services are needed for the project. Cost reimbursable compensation shall be based on Engineer’s personnel time at Engineer’s hourly labor rates attached hereto as Attachment A Hourly Fee Schedule. All direct expenses, including mileage, travel and lodging expenses, but excluding subcontract expenses, applied to the Additional Services of Engineer, shall be paid at invoice or internal office cost plus a ten percent (10%) service charge. Subcontract expenses shall be paid at direct cost plus a ten percent (10%) service charge. All sales, use, value added, business transfer, gross receipts, or other similar taxes will be added to Engineer's compensation when invoicing Owner.
