Contractor’s Performance Warranties Contractor represents and warrants to the State that:
(i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment.
(ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure.
(iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
CONTRACTOR’S PERFORMANCE 2.21.1 Contractor shall make citizen satisfaction a priority in providing services under this Agreement. Contractor shall train its employees to be customer service-oriented and to positively and politely interact with citizens when performing contract services. Contractor’s employees shall be clean, courteous, efficient, and neat in appearance and committed to offering the highest quality of service to the public. If, in the Director’s opinion, Contractor is not interacting in a positive and polite manner with citizens, he or she shall direct Contractor to take all remedial steps to conform to these standards
Condition of the Contractor’s Property or Equipment The Contractor shall make the Property and/or equipment available to the Judicial Council, pursuant to the terms and conditions set forth in this Agreement. The Contractor shall immediately remedy any problem with the Property’s physical plant or equipment that impairs or diminishes the quality of the Program. The Contractor shall ensure the appropriate hot water, heating, and ventilation is provided at the Property during the Program, inclusive in the prices set forth herein.
Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.
Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.
LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents.
(b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons.
(c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.
Lessor's Right to Perform for Lessee If Lessee fails to make any payment of Rent required to be made by it hereunder or fails to perform or comply with any of its agreements contained herein, then (but in each case, except in the case of failure to pay Rent or in the case of failure to maintain insurance as required hereunder, no earlier than the fifteenth day after the occurrence of such failure, whether or not it shall yet constitute an Event of Default hereunder) Lessor may itself make such payment or perform or comply with such agreement but shall not be obligated hereunder to do so, and the amount of such payment and the amount of the reasonable expenses of Lessor incurred in connection with such payment or the performance of or compliance with such agreement, as the case may be, together with interest thereon at the Past Due Rate, shall be deemed Supplemental Rent, payable by Lessee upon demand.
Performance by Contractor The Contractor, at the Contractor's own expense, shall, except as herein otherwise specifically provided, furnish and provide all and every kind of labour and superintendence, services, tools, implements, machinery, plant materials, articles and whatsoever is necessary for the due execution of the work. The Contractor shall fully construct and erect the work in the most thorough, professional and substantial manner, in every respect to the satisfaction and approval of the Engineer. The Contractor shall complete the work within the time specified herein and deliver it to the Minister in the manner and upon the terms and conditions of the Contract.
