County of Orange Child Support Enforcement Subrecipient certifies it is in full compliance with all applicable federal and state reporting requirements regarding its employees and with all lawfully served Wage and Earnings Assignment Orders and Notices of Assignments and will continue to be in compliance throughout the term of the Contract with the County of Orange. Failure to comply shall constitute a material breach of the Contract and failure to cure such breach within 60 calendar days of notice from the County shall constitute grounds for termination of the Contract.
Responsibilities of the City The City’s Contract Manager will be responsible for exercising general oversight of the Contractor’s activities in completing the Scope of Work. Specifically, the Contract Manager will represent the City’s interests in resolving day-to-day issues that may arise during the term of this Contract, shall participate regularly in conference calls or meetings for status reporting, shall promptly review any written reports submitted by the Contractor, and shall approve all invoices for payment, as appropriate. The City’s Contract Manager shall give the Contractor timely feedback on the acceptability of progress and task reports.
Regulation of School District Expenses The Board regulates the reimbursement of all travel, meal, and lodging expenses in the District by resolution. No later than approval of the annual budget and when necessary, the Superintendent will recommend a maximum allowable reimbursement amount for expenses to be included in the resolution. The recommended amount should be based upon the District's budget and other financial considerations.
Legal Action; Utilization of Special Receivership Powers The Assuming Institution shall notify the Receiver in writing (such notice to be given in accordance with Article V below and to include all relevant details) prior to utilizing in any legal action any special legal power or right which the Assuming Institution derives as a result of having acquired an asset from the Receiver, and the Assuming Institution shall not utilize any such power unless the Receiver shall have consented in writing to the proposed usage. The Receiver shall have the right to direct such proposed usage by the Assuming Institution and the Assuming Institution shall comply in all respects with such direction. Upon request of the Receiver, the Assuming Institution will advise the Receiver as to the status of any such legal action. The Assuming Institution shall immediately notify the Receiver of any judgment in litigation involving any of the aforesaid special powers or rights.
Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.
12.2. The District shall verbally or in writing advise Architect if the District becomes aware of any fault or defect in the Project, including any errors, omissions or inconsistencies in the Architect’s documents. Failure to provide such notice shall not relieve Architect of its responsibility therefore, if any.
12.3. Unless the District and Architect agree that a hazardous materials consultant shall be a Consultant of the Architect, the District shall furnish the services of a hazardous material consultant or other consultants when such services are requested in writing by Architect and deemed necessary by the District or are requested by the District. These services shall include: asbestos and lead paint survey; abatement documentation; and specifications related to said matters, which are to be incorporated into bid documents prepared by Architect. If the hazardous materials consultant is furnished by the District and is not a Consultant of the Architect, the specifications shall include a note to the effect that the hazardous materials consultant’s specifications are included in the Architect’s bid documents for the District’s convenience and have not been prepared or reviewed by the Architect. The note shall also direct questions about the hazardous materials consultant’s specifications related to asbestos and lead paint survey and/or abatement documentation to the preparer of the hazardous materials consultant’s specifications.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Program Requirements Provided At No Charge to the Judicial Council A. The Contractor shall provide the following items during the Program at no charge to the Judicial Council:
Invoicing for Charges Against the Judicial Council’s Master Account A. The Contractor shall establish a Master Account for the Judicial Council’s charges provided for under the exhibits of this Agreement.
B. Charges to the Master Account shall be settled with Citibank CMC, as defined herein.
C. The Contractor's final invoice for the Master Account shall include the Judicial Council Contract Number set forth on the face of this Agreement and shall be itemized to show the applicable and allowable charges by date and event/category/activity and number served, as appropriate.
D. For performing the Work of this Agreement, the Contractor shall xxxx the Judicial Council for the total actual charges against the Master Account, based upon the prices stated herein and itemized to provide the following details, if applicable:
i. Sleeping room charges as set forth in Exhibit C;
ii. Meeting room rental charges as set forth in Exhibit D;
iii. Food and beverage charges as set forth in Exhibit E; and/or
iv. Charges for miscellaneous requirements as set forth in Exhibit F.
E. If the Contract is terminated in whole or in part, pursuant to either the termination for cause provision or the Judicial Council’s obligation subject to availability of funds provision, as set forth in Exhibit A, the Contactor shall xxxx the Judicial Council for only those applicable and allowable charges accrued up to the effective date of termination, itemized as set forth above in this provision.
F. If the Contract is terminated pursuant to the Termination Fee charge provision, as set forth in Exhibit B, the Contractor shall xxxx the Judicial Council for the allowable and applicable Termination Fee, as set forth in Table 2, below, and shall offset the Termination Fee by rental charges for the meeting and function rooms that the Contractor received from Third Parties during the Program
Chief Executive Office; Change of Name; Jurisdiction of Organization (a) The exact legal name, type of organization, jurisdiction of organization, federal taxpayer identification number, organizational identification number and chief executive office of such Grantor is indicated next to its name in Sections I.A. and I.B. of the Perfection Certificate. Such Grantor shall furnish to the Collateral Agent prompt written notice of any change in (i) its corporate name, (ii) the location of its chief executive office, its principal place of business, any office in which it maintains books or records relating to Collateral owned by it or any office or facility at which Collateral owned by it is located (including the establishment of any such new office or facility), (iii) its identity or type of organization or corporate structure, (iv) its federal taxpayer identification number or organizational identification number or (v) its jurisdiction of organization (in each case, including, without limitation, by merging with or into any other entity, reorganizing, dissolving, liquidating, reincorporating or incorporating in any other jurisdiction). Such Grantor agrees (A) not to effect or permit any such change unless all filings have been made under the UCC or otherwise that are required in order for the Collateral Agent to continue at all times following such change to have a valid, legal and perfected first priority security interest in all the Collateral (subject to, with respect to priority, Permitted Encumbrances having priority by operation of law) and (B) to take all action reasonably satisfactory to the Collateral Agent to maintain the perfection and priority of the security interest of the Collateral Agent for the benefit of the Credit Parties in the Collateral intended to be granted hereunder. Each Grantor agrees to promptly provide the Collateral Agent with certified Organization Documents reflecting any of the changes described in the preceding sentence.
(b) The Collateral Agent may rely on opinions of counsel as to whether any or all UCC financing statements of the Grantors need to be amended as a result of any of the changes described in SECTION 4.3(a). If any Grantor fails to provide information to the Collateral Agent about such changes on a timely basis, the Collateral Agent shall not be liable or responsible to any party for any failure to maintain a perfected security interest in such Grantor’s property constituting Collateral, for which the Collateral Agent needed to have information relating to such changes. The Collateral Agent shall have no duty to inquire about such changes if any Grantor does not inform the Collateral Agent of such changes, the parties acknowledging and agreeing that it would not be feasible or practical for the Collateral Agent to search for information on such changes if such information is not provided by any Grantor.
Litigation, Labor Controversies, etc There is no pending or, to the knowledge of the Borrower, threatened litigation, action, proceeding, or labor controversy affecting the Borrower or any of its Subsidiaries, or any of their respective properties, businesses, assets or revenues, which could reasonably be expected to have a Material Adverse Effect, except as disclosed in Item 6.7 ("Litigation") of the Disclosure Schedule.
